This is a service / maintenance or supply contract in San Francisco, California. Contact the soliciting agency for additional information.

Bid Valid Ninety (90) Calendar Days Liquidated Damages TBD on Specific Projects Estimated Bid Value 30000000 Start/Delivery Date ASAP Project Duration Three (3) years {from OGC approval of MEA} Bid 0.0% Performance 100.0% Payment 100.0% Pre-Bid Meeting No Online Q&A No The Board of Trustees of the California State University is requesting Statements of Qualifications (SOQ) from interested and qualified general contractors (Respondents) to provide design-build and construction manager services with lump sum pricing for the design, preconstruction, and construction of multiple projects under a master enabling agreement. Respondents must be prequalified with the Trustees one day prior to the SOQ due date, or Trustees will not consider the Respondents SOQ submissions. All Respondents shall submit their prequalification applications online no less than ten (10) business days prior to the SOQ submittal due date above. The Trustees require three percent Disabled Veteran Business Enterprise participation in all contracts. The Trustees are granting a DVBE Bid Incentive, to proposers who propose to exceed the required 3% DVBE participation. The DVBE Incentive is calculated as a percentage of the highest Technical Proposal Score, and the resulting number of points are added to each propoer Adjusted Technical Proposal Score. The DVBE Incentive amount is added to the required 3% participation as follows: 1%(=total of 4.00% to 4.99% DVBE participation), 2% (=total of 5.00% to 5.99% DVBE participation) or 3% (=total of 6.00% or more DVBE participation) of the highest Technical Proposal Score. The three percent participation requirement applies to the overall TO-CA MEA. When it nears time to bid trades, the selected construction manager shall contact the Trustees DVBE Coordinator at (415) 338-2547; Email: stevenchang@sfsu.edu. This TO-CA MEA contains multiple public works projects, which are subject to prevailing wage rate laws (see Contract General Conditions, Prevailing Wage). All contractors and all tiers of subcontractors bidding on this project shall register to bid public works projects with the Department of Industrial Relations (DIR), and maintain current this registration pursuant to Labor Code Section 1725.5. Trustees Budget for All Projects: NTE $30,000,000.00 Trustees Maximum Budget per Project: NTE $7,000,000.00 Maximum Term of TO-CA MEA: Three (3) years {from OGC approval of MEA} Contractor License Requirement: B