Site work and paving for a road / highway in Elmore, Ohio. Completed plans call for site work for a road / highway; and for paving for a road / highway.

No proposal will be considered unless it is made on the blanks furnished by the County. No bidder shall take any exception to any requirement of the specifications. Each proposal must contain the full name of the party or parties submitting the proposal and all persons interested therein. The owner intends and requires that this project be completed no later than October 30, 2020. All contractors and subcontractors involved with this project will, to the extent practicable use Ohio Products, materials, services, and labor in the implementation of their project. Additionally, contractor compliance with the equal employment opportunity requirements of Ohio Administrative Code Chapter 123, the Governor's Executive Order of 1972, and Governor's Executive Order 84-9 shall be required. Each bid must be accompanied by a bid guaranty. The bid guaranty may be of two forms: 1) A Bid Guaranty and Contract Bond using the form in the Contract Documents or 2) a certified check, cashier's check or letter of credit in favor of Ottawa County, Ohio, in the amount of 10% of the bid. If the contract is awarded a Contract Bond will be required, which is a 100% payment and performance bond. The bid guaranty must meet all requirements of Section 153.54 of the Ohio Revised Code and the Instructions to Bidders. All work shall be carried out in compliance with all federal, state and local laws, rules and regulations that apply to the work. The Board of County Commissioners reserves the right to reject any or all bids, and to waive any irregularities in a bid, or to accept that bid which in the judgment of proper officials is to the best interest of the County. The Board also reserves the right to delay the award of this project until July as per O.R.C. Section 153.12A.