Demolition, site work and new construction of a mixed-use development in San Antonio, Texas. Completed plans call for the construction of a 16,270-square-foot fire / police facility; for the demolition of a fire / police facility; and for site work for a fire / police facility.

**As of November 05, 2020, project has not been awarded. A timeline for award has not yet been established.** The Fire Station #24 Replacement project, located at 2265 Austin Highway, provides for a new fire station of approximately 16,000 square-feet, comprised of three (3) apparatus bays, one EMS bay, a kitchen, dining and living areas, dormitories, offices, an exercise room, laundry rooms and associated site and utilities work. The site improvements include concrete paved fire apparatus circulation and parking for 35 cars, driveways, fire lane, service areas, water, fire line and fire sprinkler, sanitary sewer, storm drainage, electrical and telecommunications services. Additionally, one (1) alternate is being proposed: 1. Provide brick and stone masonry veneer and stucco exterior facing materials as shown on Sheets A10.00 thru A10.13 in lieu of metal wall panel exterior facing included in the base bid proposal. Calendar Days: Respondent understands and agrees that this is a 12 month construction contract (365 Calendar Days). Contract Budget: The estimated budget for this contract is $6,200,000.00 Liquidated Damages - Substantial Completion - 365 Calendar Days - $1,800.00 per day Final Completion - 30 Calendar Days $1,000.00 per day The selected Respondent shall comply with City Ordinance Number 2008-11-20-1045, concerning Wage and Hour Labor Standard Provisions for City of San Antonio Construction Projects (amending City Ordinance Number 71312). This is a Public Works Contract and Chapter 2258 of the Texas Government Code requires that not less than the prevailing wage rate for work of a similar character in this locality shall be paid to all laborers, workmen and mechanics employed in the construction of this Project. This prevailing wage requirement includes overtime regulations. Respondent shall refer to the General Wage Decision Number TX20200231 02/14/2020, attached hereto, incorporated by reference herein and labeled as "Exhibit B". Upon City Council approval, the selected Respondent shall furnish City with payment and performance bonds, in accordance with the provisions of Chapter 2253 of the Texas Government Code required for this Project have been attached hereto, incorporated by reference herein and labeled as "Exhibit C" Respondents who join the WebEx Pre-Submittal Conference are highly encouraged to email the solicitation's point of contact person confirming Respondent attendance and participation through the WebEx. Certified SBE firms (see Small Business Enterprise definition) headquartered or having a Significant Business Presence within the San Antonio Metropolitan Statistical Area responding to this solicitation as Prime CONTRACTORs proposing at least 51% SBE participation (Prime and/or Subcontractor) will receive ten (10) evaluation criteria points, and Certified M/WBE firms (see Minority/Women Business Enterprise definition) headquartered or having a Significant Business Presence within the San Antonio Metropolitan Statistical Area responding to this solicitation as Prime CONTRACTORs proposing at least 51% M/WBE participation (Prime and/or Subcontractor) will receive five (5) evaluation criteria points. Respondent must submit questions concerning this RFCSP through the CivCast website until 4:00 p.m. CST, July 13, 2020. Questions received after the stated deadline shall not be answered.