Renovation of a mixed-use development in Palm Beach Gardens, Florida. Completed plans call for the renovation of a water / sewer project; and communication facility.

*Project has been awarded to C.C. Control Corp* The Work is Generally Described as Follows. The Project Includes Conversions and Improvements to the Remote Telemetry Units (Rtu) at Seacoast Utility Authority. The Project Includes Plc Programming and Modifications for Twenty-nine (29) Reclaimed Water Distribution and Metering Stations and Installation of a New Master Cellular Antenna and Radio at the Operations Building. The Rtu's Will Be Converted From a Vhf Radio Communications System to Cellular Technology. The Rtus Will Be Converted From a Proprietary to an Open-architecture System. The Work Also Includes Coordinating With the Owner to Establish Communication for Scada/hmi Programming. Contractor Shall Furnish and Install New Rtu Panels, Modify Existing Rtu Panels, New Cellular Antennas, Radios, Conduit, Wiring, Testing, Start-up, and All Other Ancillary Work and Equipment for a Fully Functioning System as Shown on the Drawings and Specifications. A Cashiers Check or a Bid Bond in a Sum Not Less Than Five Percent (5%) of the Amount of the Bid, Made Payable to Seacoast Utility Authority (Bid Security) Shall Accompany Each Bid as a Guarantee That the Bidder Will Not Withdraw From the Competition After the Opening of Bids. The Sureties for the Bid Bond and Public Construc Tion Bond Must Be an Entity Included in the Most Recent United States Department of Treasury List of Acceptable Sureties and Be Authorized to Issue Surety Bonds in Florida. Bid Security Shall Be in a Single Acceptable Instrument. If Bid Security is Made by Cashier's Check, the Conditions Contained in the Bid Bond Shall Nonetheless Apply to the Cashiers Check as They Relate to Forfeiture or Damages. No Bids May Be Withdrawn for a Period of Ninety (90) Days After the Day of Bid Opening. The Cost of Bid Preparation is Considered an Operational Cost of Bidders and Shall Not Be Passed on or Borne by the Owner. The Successful Bidder, Who is Awarded the Contract, Will Be Required to Furnish a Public Construction Bond in Full Contract Amount in Accordance With Florida Statute Section 255.05, and to Submit a Certificate of Insurance Demonstrating Conformance With the Contract Documents. For This Project Builder's Risk Insurance is (is Not) Required. Failure to Provide the Required Bond or Insurance(S) Shall Be Grounds to Reject the Bid and Shall Result in the Owner Retaining the Bid Security to the Full Extent of Owner's Damages. Bids Shall Be Prepared, Addressed and Submitted in Compliance With Detailed Instructions as Set Forth in the Instructions to Bidders All Forms and Questionnaires Must Be Filled Out Completely as Instructed. Failure to Complete the Bid Forms as Instructed and Provide the Requested Information, or to Fully Execute the Bid, Shall Be Grounds for Rejection of the Bid and Shall Result in the Owner Retaining the Bid Security to the Full Extent of Owner's Damages. Seacoast Utility Authority Reserves the Right to Reject Any or All Bids in Whole or in Part, With or Without Cause, to Waive Irregularities, Variances, Deviations, Technical Errors and Informalities to the Extent Permitted by Law, or to Accept the Bid Which in Its Judgment Best Serves the Public Interest. Contract time is 330 days for Substantial and 360 days for Final Completion.