Site work for a water / sewer project in Port St Joe, Florida. Completed plans call for site work for a water / sewer project.

Please disregard the second sentence of Article 22 of the Instructions to Bidders. Sales tax is to be included in the bid per the Sales Tax Exempt Purchasing Agreement. Please note on Sheet C4.4 the reference to 8” SS gate and check valves is incorrect. Standard iron-body valves meeting the technical specifications are to be used. The City of Port St. Joe will receive sealed bids from any qualified person, company or corporation interested in constructing: Long Avenue Water and Sewer Improvements This project located in Port St. Joe, Florida includes construction of a new sewage lift station constructed near the intersection of First Street on Langston Drive. The new duplex submersible pump station will be capable of pumping 1,000 gallons per minute (gpm) at 40 feet of head and will replace the existing station known as the First Street Station. Temporary bypass pumping will be required for construction of a new 21-inch diameter gravity sewer from the existing station to the new. Restoration will include asphalt roadway construction, concrete sidewalks, sodding and grassing. The existing dry pit-wet pit station will be demolished following commissioning of the new station. This project will also include rehabilitation of gravity sewer, manholes, and laterals on Long Avenue using the Cure-In-Place-Pipe (CIPP) method. Replacement of approximately 4,000 LF of existing force mains with 12 PVC force main is also included from 5th Street to 16th Street and approximately 11,000 LF of 10 water main from 1st Street to the Middle School. The completion date for this project will be 330 days for Substantial Completion and 360 days for Final Completion from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day. Please indicate on the envelope that this is a sealed bid, for the RFP 2021-06Long Avenue Water and Sewer Improvements. The City of Port St. Joe is an Equal Opportunity, Affirmative Action, Drug Free Work Place Employer. The City of Port St. Joe reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in their best interest. All bids shall remain firm for a period of sixty days after the opening.