Site work and new construction of a fire / police facility in Pinson, Alabama. Completed plans call for the construction of a fire / police facility; and for site work for a fire / police facility.

Point Fire Station No. 3 Center Point Fire District Pinson Valley Fire Station CD19-030-M04-PVFS Architect Job No. 20-38 Due to the current COVID-19 meeting restrictions, we request that: ALL BIDS ARE TO BE DROPPED OFF OR MAILED TO THE Office of the Architect: Lathan Associates Architects, PC, 300 Chase Park South, Suite 200, Hoover, AL 35244 IT IS THE RESPONSIBILITY OF THE BIDDER TO ASSURE THAT BIDS ARE PRESENTED AT THE TIME OF THE BID. CONTRACTORS MUST NOTIFY THE ARCHITECT IF A BID IS TO BE RECEIVED BY MAIL, ETC. All minority business enterprises (MBE) and disadvantaged business enterprises (DBE) are encouraged to submit bids. Bid documents are on file and will be available for examination at the Office of Lathan Associates Architects, P.C., 300 Chase Park South, Suite 200, Hoover, AL 35244. Prior to issuance of plans and specifications, all Contractors must provide evidence that they are properly licensed for the classification of work for this project. Evidence shall be in the form of a copy of current license clearly indicating all classifications, or sub-classifications, bid limits, license number; and expiration date. General Contractors will then be placed on Official Bidders List. Deposit will be refunded in full on the first two sets issued to each General Contractor Bidder upon the return of documents in reusable condition within ten (10) days after receipt of bids. Additional sets of drawings/ specifications and digital copies will be available to General Contractors for purchase directly from the documents printer: Alabama Graphics. Addenda and other proposal information will be issued only to holders of drawings and specifications distributed by the Architect and on the Official Bidders List. Release of contract documents to the bidder does not imply acceptance of the bidder's qualifications by the Owner or Architect. General Contractors who obtain drawings and wish to withdraw from the Bidders List must do so in writing to the office of the Architect prior to bid date, otherwise deposit will be forfeited. Deposit will be refunded in full on sets issued to each General Contractor Bidder submitting a bonafide bid, upon the return of documents in good, reusable condition within ten (10) days after receipt of proposals. Bids received from General Contractors who are not on the Official Bidders List may not be accepted or opened. Lathan Associates Architects, P.C. makes no guarantee for plans and specifications obtained by Contractors and Vendors from sources other than the printed contract documents provided by their firm. Contractors and Vendors who base their pricing from contract documents obtained from other electronic sources, either in part or whole, do so at their own risk. This project will be funded in with Federal Community Development Block Grant Funds. Attention is called to the fact that not less than the minimum salaries and wages as set forth in the contract documents must be paid on this project, and that the contractor must ensure that employees and applicants for employment are not discriminated against because of their race, color, sex, age, religion, national origin, disability, or veteran status. Bids must be submitted on proposal forms furnished by the Architect or copies thereof, issued either with the original contract documents or by addendum. General Contractors shall not use Proposal Forms other than those provided in the contract documents. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975. The Bidder must display current General Contractor's License Number on the outside of the sealed envelope in which the proposal is delivered or it will not be considered by the Architect or Owner. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. The Jefferson County Commission reserves the right to reject any or all bids or to waive any informalities in the bidding.