Renovation of a military facility in Montgomery, Alabama. Completed plans call for the renovation of a military facility.

Job #: ANG# FAKZ182351 / SSL# 18073 Amendment 4 will Inorporate Addendum #2, include the J&A for brand name sole source items, incoporate answers to RFI's and change the RFI acceptance date. All Amendment must me acknowledged on page 2 of the Standard Form 1442. Repair Fuel Cell, Bldg 1203 F-35A Repair Fuel Cell, Building 1203, Project Number FAKZ182351. The 187th Fighter Wing intends to aw ard a firm fixed-price contract for services to repair fuel cell, bldg 1203, as per Specifications and Draw ings Dated 1 April 2021. Project Number FAKZ182351 w ill include modification of the existing Fuel Cell, building 1203, architectural, structural, mechanical, plumbing and electrical systems as required to support the F-35A airframe. The magnitude is betw een $1,000,000 and $5,000,000. The North American Industry Classification System (NAICS) for this project is 236220. The Small Business Size Standard is $39,500,000. This aw ard is 100% set aside for Small Business. Funds are not presently available for this contract. Currently the Government anticipates funds w ill become available prior to, but no later than, midnight 30 September 2022. This action has been identified on the National Guard priority list for aw ard if funds become available and are w ithin an aw ardable range. Aw ard w ill be made to the responsible bidder w hose bid conforms to the invitation for bids and is most advantageous to the Government considering only price and price related factors. F-35A Repair Fuel Cell, Building 1203, Project Number FAKZ182351. The 187th Fighter Wing intends to aw ard a firm fixed-price Description of the Project: This project involves modification of the existing Hanger, building 1203, architectural, structural, mechanical, plumbing and electrical systems as required to support the F-35A airframe. The work will include the installation of a new split system air conditioning unit. It will also include the extension of the existing equipment mezzanine, a new air compressors, a new breathing air system. The project plans for the installation of a new 270 VDC electrical converters, 480V AC receptacles and other power devices to support F-35A maintenance activities. The project also includes the replacement of the existing facility transformer and main switchgear to support increase power requirements. There will be minor site demolition and repair to accommodate the electrical upgrades. The Intrusion Detection System (IDS), Access Controls, CCTV and telecommunication cabling and receptacles will also be upgraded. for services to repair fuel cell, bldg 1203, as per Specifications and Draw ings Dated 1 April 2021. Project Number FAKZ182351 w ill include modification of the existing Fuel Cell, building 1203, architectural, structural, mechanical, plumbing and electrical systems as required to support the F-35A airframe. The magnitude is betw een $1,000,000 and $5,000,000. The North American Industry Classification System (NAICS) for this project is 236220. The Small Business Size Standard is $39,500,000. This aw ard is 100% set aside for Small Business. Funds are not presently available for this contract. Currently the Government anticipates funds w ill become available prior to, but no later than, midnight 30 September 2022. This action has been identified on the National Guard priority list for aw ard if funds become available and are w ithin an aw ardable range. Aw ard w ill be made to the responsible bidder w hose bid conforms to the invitation for bids and is most advantageous to the Government considering only price and price related factors. NOTICE OF PRE-BID CONFERENCE AND SITE VISIT: 4.1 A pre-bid conference will be conducted 26 April 2022, 10:00 am Central Time for the purposes of briefing on the bid requirements and answering questions regarding this solicitation. This conference will be held at 5187 Selma Highway, Montgomery, Al 36108-4824, in the building 1502 Wing Auditorium classroom. THIS IS THE ONLY TIME A SITE VISIT WILL BE held Interested Contractors are highly encouraged to attend .The site visit will be held following the conference. All attendees, will be required to wear a mask, and comply with all social distancing guidelines. 4.2 Due to security conditions, all offerors must register to attend this conference and site visit. Complete the Entry Authority List (EAL) that is posted with this annoucment and email it to stephen.shanks.1@us.af.mil; william.k.hall14.mil@army.mil and karey.l.elias.civ@army.mil. 4.3 This information must be provided in advance, 3 business days prior to the meeting, in order to ensure access to the military base and conference site and ensure adequate seating for the conference attendees. Even if you have access to the base you must register to ensure adequate seating. The furnishing of the above information is voluntary; however, your failure to furnish all or part of the requested information may result in the Government's denial of your access to the pre-proposal conference. This information will be provided to the Base Security Forces who will authorize your entrance to the site. Instructions to Bidders: 2.1 You are invited to submit a bid in response to our Invitation for Bids (IFB) W50S6N-22-B-0002, F-35 Repair Fuel Cell, Building 1203, Project Number FAKZ182351. 2.2 As a result of this solicitation, the Government intends to award a Firm Fixed Price (FFP) contract resulting from this solicitation to the responsible bidder whose bid, conforming to the invitation for bids, will be most advantageous to the Government, considering only price. 2.3 This solicitation is set-aside 100% for small business. 5.1 Submit all questions in the format shown below by email to the contracting office at the addresses show below. Do NOT contact AE or Engineering personnel directly. Doing so will only delay your answer. All questions must come through the Contracting Office. Subject Line: Reference No. SOLICITATION W50S6N-22-B-0002 Email: stephen.shanks.1@us.af.mil; william.k.hall14.mil@army.mil and karey.l.elias.civ@amry.mil If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to: Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid. (b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.- (c) The amount of the bid guarantee shall be 20 percent of the bid price or $3 million whichever is less.- (d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.- (e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document. MBE (29.9%), WBE (6.9%), SBE (100%) 1. Installation of a new split system air conditioning unit to provide cooling to the existing Corrosion Control Maintenance Bay. 2. Extension of the existing equipment platform/mezzanine in Stripping Room as required to accomodate the new interior air handler for the Corrosion Control Maintenance Bay. 3. Installation of new air compressors, extension of compressed air lines, and relocation of air drops in maintenance bays to meet F-35 aircraft/shop air requirements. 4. Installation of new breathing air system to support fuel tank maintenance activities. 5. Installation of new 270 VDC electrical converters, 480V AC receptacles, and other power devices required to support F-35 maintenance activities. 6. Replacement of existing facility transformer and main switchgear to support increases power requirements associated with the F-35 electrical requirements. 7. Minor site demolition and repair to accomodate electrical upgrades. Intrusion Detection System (IDS), Access Controls, and CCTV: 1. The IDS system must be fully compatible with the existing USAF approved Advantor IDS Annunciator located in the 187th SFS BDOC. 2. As part of the base bid, the contractor is responsible for engaging Advantor Systems Cooperation (which is a sole source security system) for the procurement (purchase) and installation of the IDS, Access Controls, and CCTV systems. Refer to limited source justification included in the solicitation documents furnished by the Government. 3. The base bid shall include all plant, labor, and materials to provide all collateral support as required by Advantor (in addition to collateral support indicated in the contract documents) for installation of a fully operational IDS and CCTV systems as defined by Advantor System Corporation Submit all questions in the format shown below by email to the contracting office at the addresses show below. Do NOT contact AE or Engineering personnel directly. Doing so will only delay your answer. All questions must come through the Contracting Office. Subject Line: Reference No. SOLICITATION W50S6N-22-B-0002 Email: stephen.shanks.1@us.af.mil; william.k.hall14.mil@army.mil and karey.l.elias.civ@amry.mil *The Government received the following attached RFI and provided a response to it. No other changes have been made. Bid Date remains on July 7, 2022 please be sure to review all current Amendments there are currently 5. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.