Site work for a municipal facility in Round Rock, Texas. Completed plans call for site work for a municipal facility.

LIQUIDATED DAMAGES: Time is of the essence in the performance of the contract; therefore, the Contractor shall strictly adhere to the Contract delivery schedule. No changes in the delivery schedule shall be effective unless in writing executed by both City and the Contractor. The parties agree that if, due to no fault of the City, delivery of any material or performance of any service is delayed beyond the time specified in the Contract, the actual damages sustained by the City because of such a delay will be uncertain and difficult to determine, and that the reasonably foreseeable damage incurred by the City agrees to stipulate to be 5% of total project cost per calendar day. The Contractor therefore agrees to pay, and the City agrees to accept, as liquidated damages, the sum of 5% of total project cost per calendar day for each calendar day of delay. The City has approximately 1,000,000 square feet of maintained property and occupies approximately 56 facilities. The buildings consist of both commercial and residential type structures. Facilities maintained vary and can include but are not limited to office buildings, police department, fire stations, parks facilities and parking garages. The City requires a respondent to provide on-site services including all materials and labor necessary to perform maintenance, repair, renovations, installation, or alteration for various City owned or occupied locations on an as needed basis for fence and railings work