The Contractor shall furnish all materials, labor, equipment, mobilization and incidentals required to install a new standby power generator complete with an automatic transfer switch at the LS #26 - Golden Creek located at 3340 Gillespie Street, Fayetteville, N.C. Bids will be examined promptly after opening and an award will be made at the earliest possible date. All questions regarding this project shall be submitted in writing to Nikole Bohannon, Procurement Advisor, by e-mail to nikole.bohannon@faypwc.com. All questions shall be submitted no later than 5:00 p.m., Tuesday, January 11, 2022, in order to be considered. Oral explanations and interpretations made prior to bid opening shall not be binding. It is anticipated that the responses to the questions and any necessary addendum will be issued on or before Friday, January 14, 2022. The Fayetteville Public Works Commission reserves the right to reject any and all bids, to waive any and all informalities, and to disregard all non-conforming, nonresponsive, or conditional bids. Also, The Fayetteville Public Works Commission reserves the right to request additional information from any, or all bidders for evaluation purposes. Failure or refusal to furnish additional information as requested may result in rejection of the proposal. The Parties recognize and agree that the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by PWC if the Project is not completed by the Completion Date. Accordingly, instead of requiring any such proof, Contractor and PWC agree that in the event Contractor fails to achieve Completion of the Project by the Completion Date, Contractor shall pay to PWC as liquidated damages to compensate PWC for damages related to the delayed Completion of the Project one thousand dollars ($1000.00) per day ("Liquidated Damages") for each calendar day Contractor fails to achieve completion of the work by the Completion Date.
.webp)
