Site work and new construction of a municipal facility in Opelika, Alabama. Completed plans call for the construction of a municipal facility; and for site work for a municipal facility.

Plans and specifications are for viewing purposes only. Official sets must be obtained from McKee and Associates All interested parties are invited to attend. Only bids from competent general contractors will be considered. At the time of contract award, the successful bidder must be a properly licensed general contractor. The attention of all bidders is called to the provisions of State law governing General Contractors as set forth in the Ala. Code 34-8-1, et.seq. (1975) and rules and regulations promulgated pursuant thereto. Bidders must be licensed by the Licensing Board for General Contractors when bids are submitted. All General Contractors bidding this project shall be required to visit the site and examine all existing conditions prior to submitting their proposal. All Bidders shall have general liability and workmans compensation insurance. The project shall be bid excluding taxes. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. A certified check or Bid Bond payable to the City of Opelika, Alabama in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany the bidder's sealed proposal - refer also to Instructions to Bidders. Performance and statutory labor and material payment bonds will be required at the signing of the Contract. The right is reserved by the Owner to reject all Bids and to waive irregularities. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. All bidders shall show such evidence by clearly displaying current license number on the outside of sealed envelope in which the proposal is delivered. All RFIs and RFAs regarding the bid documents shall be sent and addressed through emails found on the RFI and RFA forms in the project manual. NOTE: Only the RFI AND RFA FORMS IN THE PROJECT MANUAL WILL BE ACCEPTED. The Architect will not accept inquires via telephone or fax. Completion Time: See scope of work in Project Manual. Supervision: Contractor to provide Superintendent(s) to ensure proper supervision for all work. Architect: McKee & Associates Architects, Inc., 631 South Hull Street, Montgomery, AL 36104, Phone: 334-834-9933 The bidder's proposal must be submitted on the complete original proposal furnished to him/her by the City of Opelika. All information in the proposal must be completed by the bidder for the proposal to be accepted. As a condition for award, the business entity and its subcontractors shall not knowingly employ or hire an unauthorized alien within the State of Alabama. The awarded business entity must provide documentation of enrollment in the E-Verify program. The business must participate in the E-Verify program for the length of the contract. Envelopes containing bids must be sealed, marked, addressed as follows, and delivered to: Lillie Finley, Purchasing-Revenue Manager, City of Opelika, 204 South 7th Street, P.O. Box 390, Opelika, Alabama 36803-0390.