Site work and paving for a road / highway in Chillicothe, Ohio. Completed plans call for site work for a road / highway; and for paving for a road / highway.

Project 538-20-204 Repave Dobson, Taft, Roland, and Hines Roads at the Chillicothe VA Medical Center, Chillicothe, OH. Scope of Work: Contractor shall completely prepare site for building operations, including demolition and removal of existing items, furnish labor, materials, and equipment necessary to perform all work for subject project as required by drawings and specifications. The work primarily consists of asphalt pavement repairs including partial and full depth repairs to the subgrade as well as mill and overlay. The work shall be phased to accommodate the Medical Centers on-going operations. Work includes temporary traffic control requirements and setting up detours for all phases of work Base bid work to be completed within 120 calendar days after receipt of Notice to Proceed (NTP). All work shall be coordinated with the VA Contracting Officer (CO) and Contracting Officer's Representative (COR). This is a 100% Set-Aside for Service-Disabled Veteran-Owned Small-Business (SDVOSB). Bidders must be verified in the VIP database (http://www.vip.vetbiz.gov) at the time of bid submission to be considered for award. An Award will only be made to an eligible SDVOSB firm in the VIP database at the time of award. The NAICS Code for this project is 237310. The Business Size Standard is $39.5 Million. See VAAR 852.219-10 for Contractor performance requirements for this NAICS Code. Project magnitude is between $500,000.00 and $1,000,000.00. A site visit will be conducted on May 16, 2022, at 10:00 A.M.(EST). See FAR 52.236-27 for details. Cut-off date and time to submit electronic Request for Information (RFIs) is May 26, 2022, at 4:00 P.M. (EST). Submit all RFIs to: myron.carson@va.gov. Telephonic RFIs will not be entertained/responded to. Bids are to be submitted electronically via email, addressed to the Contracting Officer. Please email your bid to: myron.carson@va.gov no later than June 9, 2022 @ 10:00 A.M. EST. Bid Bond seal and signatures MUST be legible. On Page 2 of the SF1442 you shall insert your Cage Code Number and fill in your Bid Prices in the appropriate blocks. NOTICE: The VA and/or a third party (support contractor) may require access to VA contractor records to assess contractor compliance with the limitations on subcontracting requirement included in VAAR 852.219-10. See Limitations on Subcontracting - Monitoring and Compliance (JUN2011) located in the General Conditions Section of this solicitation. Limitations on Subcontracting Agreement must be signed and returned prior to award. The solicitation includes specifications, drawings, wage determination, and other items by attachment (See list at end of this document). All attachments provided with the solicitation and any amendment(s) thereto are incorporated into the solicitation and any resulting contract. SITE VISIT FOR CONSTRUCTION SOLICITATION 36C25022B0022: A one-time site visit will be conducted for this requirement. It is recommended (but not required) that all interested and eligible offerors attend this site visit. As a site visit can be beneficial to potential offerors, offerors are encouraged to take advantage of this site visit opportunity. Purpose: The overall purpose of this site visit is to give potential offerors a "firsthand" look of the construction site in which future construction services will be conducted. Scope: The site visit is for viewing purposes only of any possible equipment, the site itself, and the environment in which future construction will be conducted. Any photographs taken must not include photos of VA staff or patients and will be strictly monitored during the site visit. Training will not be provided or conducted during the site visit. Questions about project requirements and/or this solicitation shall be submitted in writing in accordance with the Request for Information (RFI) instructions listed in the solicitation and shall be submitted within the time windows specified to the point of contact indicated. Arrival: It is recommended that attendees be punctual and arrive no later than 10 minutes prior to the start time of the site visit to allow for unexpected delays or occurrences. The site visit is expected to start on time on the scheduled date. Special accommodations will not be made for late attendees to include waiting for potential attendees to arrive. Parking: Parking for site visit attendees is not guaranteed and may or may not be available depending on mission requirements (patient volume) and/or site availability. Attire: The site visit may be conducted in a facility interior and exterior setting. Appropriate attire should be worn. NOTICE: The terms and conditions of this solicitation (to include Statement of Work requirements) shall remain the same despite an offeror's inability or unwillingness to attend the scheduled site visit for this project. An alternate date or an additional site visit opportunity shall not be provided to offerors who do not attend the scheduled site visit. Minutes, records, or proceedings information shall not be provided to any offeror once the site visit has concluded. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document. DESCRIPTION: A. The Contractor shall develop a Critical Path Method (CPM) plan and schedule demonstrating fulfillment of the contract requirements (Project Schedule), and shall keep the Project Schedule up-to-date in accordance with the requirements of this section and shall utilize the plan for scheduling, coordinating and monitoring work under this contract (including all activities of subcontractors, equipment vendors and suppliers). Conventional Critical Path Method (CPM) technique shall be utilized to satisfy both time and cost applications.