Site work and paving for a mixed-use development in Burlington, North Carolina. Completed plans call for site work for a playground / park / athletic field; sidewalk / parking lot; and for paving for a sidewalk / parking lot.

No proposal shall be considered or accepted by the City Council or City Manager unless at the time of its filing the same shall be accompanied by a deposit with the City of Burlington of a certified check on some bank or trust company insured by the Federal Deposit Insurance Corporation, in an amount equal to not less than five per cent (5%) of the proposal. In lieu of making the deposit as above provided, such bidder may file a bid bond executed by a corporate surety licensed under the laws of North Carolina to execute such bonds; conditioned that the surety will upon demand forthwith make payment to the City of Burlington upon said bond if the bidder fails to execute the contract in accordance with the bid bond. The Bid Bond shall be for 5% of the bid. This deposit shall be retained if the successful bidder fails to execute the contract within ten days after award or fails to give satisfactory surety as required herein A separate Performance Bond and Payment Bond each in an amount equal to one hundred per cent (100%) of the contract price will be required, using the enclosed forms. The City reserves the right to waive any informality or to reject any or all bids or to award such contract as in its judgment is deemed to the best interest of the City. The contract to be awarded for the proposed work may be extended up to fifty (50%) percent of the contract price without consent and permission of the contractor, and an additional fifty (50%) with the consent and permission of the contractor. This extension may be outside the project limits, at the discretion of the City Engineer. All extensions shall include time extensions as determined by the City Engineer based on the dollar amount of the extension in relationship to the original Contract time. Total extensions not to exceed one hundred (100%) percent of the contract price. All contractors are hereby notified that they shall be properly licensed under North Carolina State Laws governing their respective trades.