Renovation of a mixed-use development in Humble, Texas. Completed plans call for the renovation of a educational facility.

As a pre-qualification to an Offeror's qualifying for the award of contract on this work, the Offeror must complete each item of the Contractor's Qualification Statement (AIA Document A305). The Statement forms may be obtained from the Houston Chapter of the American Institute of Architects, 315 Capitol, Suite 120, Houston, Texas 77002, (713) 520-0155. In addition to the information contained in the Statement form, offerors shall also address the selection criteria issues listed under the paragraph below for Determination of Successful Respondent and Award of Contract. The Qualification Statement and references shall be submitted to Steve Aloway; saloway@huckabee-inc.com no later than 5:00 PM, MONDAY, FEBRUARY 28, 2022. A pdf copy of the A305 must also be uploaded with each Offerors proposal. Provide each reference contact name, email address, phone & fax numbers, name of Project(s) you worked for them on and name of Owner/District. Qualification statements submitted by FAX transmission will not be accepted. In the event a proposed Offeror fails to submit the specified Contractor's Qualification Statement (A305) by the specified date and time, such noncompliance shall be considered by both the Owner and Architect as a negative factor and could be grounds for disqualification at the Owner's discretion in the determination of the successful Offeror. C. The primary purposes of the evaluation process will be to: 1. Gather information for the Owner's evaluation procedure. 2. Enable the Owner and/or Architect to evaluate the Offeror's qualifications. D. After review of Proposals and Contractor's qualifications evaluation the Owner will make his decision and each Offeror will be notified once board approval has been obtained. E. In arriving at his opinion concerning the Offeror's qualifications, the Architect will use the same criteria that the Owner will use in determination of the successful Offeror as detailed hereinafter. A. The A305 Document must be accompanied by a listing of the Offeror's projects of similar size and scope during the past five (5) years. The listing shall include the project name, address, building area, contract sum, contract date, contract completion date(s), substantial completion date(s), Owner representative's name, telephone number, e-mail address and the names of the Contractor's project staff assigned to the project. In addition, the General Contractor shall include in this submission the following information regarding the Contractor's Proposed Project Team: 1. Name of the Proposed Project Executive. 2. Name of the Proposed Project Manager. 3. Names of Proposed Assistant Project Managers or Project Engineers. 4. Name of Proposed Project Superintendent. 5. Name of Proposed Assistant Project Superintendent. 6. Name of Proposed Field Engineer. 7. Names of any proposed project support staff. B. The General Contractor shall include a resume of qualifications for each of the project personnel proposed. C. In addition, include a written summary describing the roles each person will have on the project team and what percentage of time each person will dedicate to this project on a weekly basis. In addition, the contractor shall indicate where each staff member will office (onsite or main office). PN - 2021-04607-00