Site work and renovation of a multi-residential development in Huntsville, Alabama. Completed plans call for the renovation of a multi-residential development; and for site work for a multi-residential development.

Contractor will be responsible for providing all labor, tools, equipment, security, services, water, light, heat, power, transportation, and supervision necessary for the satisfactory performance of the work subject to this QSP. The attached scope of work/technical specification may or may not be all inclusive. It is HHA's intent for the apartment to be ready to rent upon completion. All quotes in excess of $25,000.00 will require a Bid Bond as required by the State of Alabama. The respondent agrees to provide HHA with a cashier's check or bank draft, payable to HHA, or a satisfactory performance bond executed by the respondent and a corporate surety qualified to do business in Alabama, in an amount equal to, but not less than five percent (5%) of the bid amount. The original, certified copy of the bid bond must be submitted with the bid All questions pertaining to this solicitation shall be submitted in writing no later than seven (7) business days before the quote due date. Written questions may be submitted by email, to the Procurement Officer, Ms. Tracie McCann, at tmccann@hsvha.org or by fax to (256) 533-6344. HHA will only respond to written questions and only be bound by its response to written questions. Oral communications are discouraged, and HHA will not be bound by any oral answers or interpretations of the QSP. If Contractor fails to complete the work within the time specified in the agreement, or any extension, the contractor shall pay to HHA as liquidated damages, the sum of $200.00 for each day of delay. (a) If HHA terminates the Contractor's right to proceed, the resulting damage will consist of liquidated damages until such reasonable time as may be required for final completion of the work together with any increased costs occasioned by HHA in completing the work. (b) If HHA does not terminate the Contractor's right to proceed, the resulting damage will consist of liquidated damaged until the work is completed or accepted. Failure to complete and submit all required information, or to add any additional requirements not acceptable to the HHA, may invalidate the quote submitted. Furthermore, the HHA shall reserve the right to reject, without consideration, alternate quotes, meaning those that do not meet the requirements of this QSP.