Site work for a municipal facility in Conroe, Texas. Completed plans call for site work for a municipal facility.

Questions Deadline: 5/4/2022 11:00 AM (CT) The Owner requires a person who submits a Proposal to submit a certified or cashiers check on a responsible bank in the state equal to five percent (5%) of the total amount of the Proposal, or a bid bond equal to five percent (5%) of the total amount of the Proposal issued by a surety legally authorized to do business in this state, as a good faith deposit to ensure execution of the Contract. For a Contract for more than $250,000, the Owner must accept a bid bond in the amount required by the Owner as a Proposal deposit. If the successful Respondent fails or refuses to enter into a proper Contract with the Owner, or fails or refuses to furnish the payment and performance bonds required by law, the Respondent forfeits the deposit. Contractor and its Surety shall be liable for liquidated damages as provided in the Contract for the failure of the Contractor to timely complete the Work within the Contract Time Requirements. Owner stipulates that as liquidated damages for delay (but not as a penalty) and, as a reasonable estimate of such damages, Contractor shall pay: Failure to Meet Substantial Completion: $250/day Failure to Meet Final Completion: $250/day An Engineers Opinion of Probable Construction Cost (OPCC) has been generated by the Principal Architect/Engineer (A/E). If an award is made, the actual Contract amount may vary. The Engineers OPCC for this project is $ 79,250.00 . This OPCC does not include any alternates, extra unit price items, or allowances shown on the Proposal Form. The Work will be Substantially Completed within 60 calendar days after the date of Notice to Proceed and Contractor shall achieve Final Completion within 30 calendar days of the date required for Substantial Completion.