Site work and new construction of a mixed-use development in Jersey City, New Jersey. Completed plans call for the construction of a educational facility.

Offerors are cautioned to commence the submittal process sufficiently ahead of time to allow for unanticipated delays resulting from things like a slow internet connection, internet outage, difficulty uploading large documents, differing system requirements, etc. All respondents are required to comply with the requirements of N.J.S.A. 10:5-31 et seq., and N.J.A.C. 17:27 et seq. Statement of Ownership Requirement: Pursuant to N.J.S.A. 52:25-24.2, Bidders shall submit a statement setting forth the names and addresses of all persons and entities that own ten percent or more of its stock or interest of any type at all levels of ownership. A Non-Collusion Affidavit and a Contractor Questionnaire/Certification also must be filed with the proposal. The proposal package will also include other documents that must be completed and returned with the proposal. Failure to complete and submit all required forms may be cause for disqualification and rejection of the proposal. The Board of Education reserves the right to reject any or all proposals pursuant to N.J.S.A. 18A:18A-2(s), (t), (x), (y), 18A:18A-4(a), 18A:18A-22, and to waive minor informalities or non-material exceptions, that may be in the best interest of the Board. All proposals solicited and received are done so pursuant to the Competitive Contracting Process. N.J.S.A. 18A:18A-4.1 et seq. The Jersey City Board of Education hereby provides public notice that Federal funds will be used to procure the goods/services as outlined in the bid specifications. The percentage of the cost of the goods/services are outlined below. Federal Program ESSER ARP III Percentage of the Total Cost of Bid One Hundred Percent (100%) As a requirement for submission of the bid, all bidders are to read the Certifications Section for Federal Contract Requirements, found at the end of the bid package. Bidders shall be responsible for the completion, execution and submission of all required Certification documents. DEADLINE FOR QUESTIONS: May 26, 2022 Project Awarded to Student Leadership Network