Site work for a water / sewer project in New Orleans, Louisiana. Completed plans call for site work for a water / sewer project.

GENERAL 1. Submit, at a minimum, an offer that conforms to the solicitation documents. By submission of an offer, the offeror unconditionally assents to the terms and conditions in this solicitation and in any solicitation attachments. Proposals offering alternative stipulations to the requirements of this solicitation will NOT be considered or accepted. 2. In accordance with FAR 36.209, all firms, prime contractors or subconsultants, involved in developing the design or specifications for this construction solicitation are not eligible and prohibited from receiving any part of this construction award. Proposals from or containing firms under these circumstances will not be considered for award. B. QUESTIONS Pre-proposal questions shall be submitted a minimum of 7 days prior to the due date and time for proposals. Submit questions only though email to both of the following: Contracting Officer, Shellie Murphy, shellie_murphy@nps.gov Contract Specialist, Zaira Lupidi, Zaira_lupidi@nps.gov C. OFFER DUE DATE AND LOCATION 1. To be considered for award, proposals must be received no later than the date and time noted in Block 13.a of the SF1442 contained in this solicitation. Offerors are responsible for confirming their proposals are received by the due date and time. D. SUBMISSION REQUIREMENTS 1. Proposals shall be submitted via email. Proposals submitted via any means other than email shall not be accepted. 2. Proposals shall be sent to all of the following: a. Contracting Officer, Shellie Murphy, shellie_murphy@nps.gov b. Contract Specialist, Zaira Lupidi, Zaira_lupidi@nps.gov c. CS_DSC_Proposal_Submission@nps.gov 3. Title subject line for all proposal submissions shall contain the solicitation number, Park-PMIS, and number of total emails, per the following example: Subj: 140P2022R0069, JELA 251674, email 1 of 2 4. Submit proposals in separate VOLUMES (I and II) in the FORMATS specified, containing CONTENTS required. Each volume shall be submitted in separate email attachments. 5. Size limits: a. Individual email attachments shall be no larger than 38 MB. b. Each email shall be no larger than 100 MB 6. Offerors shall verify receipt of proposals. Jean Lafitte National Historical Park an Preserve (JELA) PMIS 251674, Shoreline Protection a) This acquisition is being conducted via the Small Business Administration. The North American Industrial Classification System (NAICS) code and the associated small business size standard are noted in clause 52.204-8 in section "K" of this solicitation. b) Estimated Price Range: More than $10,000,000 c) Refer to section "L" for information regarding a pre-proposal site visit. d) Information and requirements stated in sections "B" through "J" & attachments noted in section "J" apply to this solicitation and the subsequent contract. e) Refer to section "L" for proposal submittal requirements. f) This is currently an unfunded requirement with a high expectation that funds will be available. When and if funds become available a contract will be awarded at that time. g) Offerors shall submit proposals and questions, and acknowledge solicitation amendments as stated in section "L" of this solicitation h) This acquisition is a Total Small Business Set-Aside. SITE VISIT (CONSTRUCTION) (FEB 1995) (a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed. (b) An organized virtual site visit and pre-proposal conference is scheduled for: September 22, 2022 at 12:00pm-1:00pm MT To participate in the virtual site visit, send an email to the Government points of contacts for this solicitation no later than September 21, 2022 at 12:00pm MT. Include the following information: Email title: "JELA 251674, Solicitation Number 140P2022R0069, Request for Virtual Preproposal Conference Participation". The email shall contain: The Name of the Participant, Company Name, Trade (ex. General Contractor, MEP, Roofer) and the email address the invitation is to be sent to. The Government will host the virtual preproposal conference using Microsoft Teams. Microsoft Teams may be downloaded to a desktop computer or smartphone at no cost prior to the conference. At the date and time set for the conference, participants will select the "join" tab in the invitation, enter their name when prompted, and will join as a participant to the conference. SCHEDULE Submit your proposed construction schedule for THIS SPECIFIC PROJECT showing completion within the required period of performance contained in this solicitation with accompanying schedule narrative. Submit your schedule in MS Project Gantt Chart format; for evaluation purposes only assume a Notice to Proceed date of November 1, 2022; and include specific activities required for this project and a clear critical path with major milestones and applicable predecessor activities. In your accompanying narrative, explain schedule logic, critical path activities, and key considerations and constraints. There is no preprinted form for this submittal.