Privately Funded
Bidding Soon
Documents Available
Publicly Funded
Addenda Available
Post-Bid
Saving Project...
Site work and paving for a road / highway in Seaside, California. Completed plans call for site work for a road / highway; and for paving for a road / highway.
The work includes, but is not necessarily limited to, the furnishing of all labor, materials, equipment, and services necessary for, and reasonably incidental to paving and signing & striping, as shown or indicated in the Drawings and Specifications. The project is located at various streets within City of Seaside, Monterey County. Upon written request of the Contractor, the Engineer will add one day to the contract completion date for each working day that in the judgment of the Engineer work cannot be performed to the specifications herein due to inclement weather conditions. The Contractor shall submit such delay request to the Engineer no later than 9:00 a.m. on the workday in question. Bidders are required to sign and submit the bid forms provided in the Proposal and Contract book. No bid will be considered unless it is made on a proposal form furnished by the City and is accompanied by a bid bond for ten percent (10%) of the bid amount. The successful bidder shall furnish a Labor and Materials Bond, a Performance Bond, and a Surety Bond. The successful bidder will be required to secure a City Business License before commencing work on the project and must possess a Class A General Contractors license or a combination of Class C-8 7 C-12 Licenses at the time the contract is awarded. The successful bidder shall furnish three separate bonds: a performance bond, a labor and materials bond and a surety bond. Each of the said bonds shall be executed in a sum equal to one hundred percent of the Contract price and issued by a bonding company with an A.M. Best rating of A- or better, or instrument of credit. The Contractor shall begin work within 15 calendar days after the Notice to Proceed has been issued by the City of Seaside. This work shall be diligently prosecuted to completion before the expiration of 65 WORKING DAYS beginning on the fifteenth calendar day after approval of the contract. The Contractor shall pay liquidated damages to the City of Seaside, the sum of $5,400 per day, for each and every calendar days delay in finishing the work in excess of the number of working days prescribed above. The City reserves the right to reject any or all bids and the right to waiver minor irregularities or informalities in any bid proposal.
Award
Roads / Highways
$1,993,300.00
Public - City
Paving, Site Work
Trades Specified
Division 00 - Lorem Ipsum
Find More Local Projects
Within 75 Miles of This Project
One Low Price
- One license and one market
- Details and key contacts on all bidding projects
- Organize your pipeline with a digital bid board
- Automatically match opportunities to your profile
- Saved searches deliver daily project leads to your email inbox
Market Pricing Around
- All Starter Product functionality
- Access to all documents (plans, specifications, and addenda)
- Access to planning projects
- Access to contact information
- Ability to Export
You’ve Reached the Free View Limit
Want to see more project and bidder data in your market? Check out our product options and see what works best for you and your business.
Come back in [[refresh_days]] to get [[project_count]] more free projects.
September 1, 2022
October 31, 2022
Multiple Locations, Seaside, CA
Related To This Project
Seaside, CA
Bid Date: Sep 28 2022
Seaside, CA
--
Seaside, CA
Bid Date: Oct 11 2022
Seaside, CA
Bid Date: Oct 25 2022
Seaside, CA
Bid Date: Dec 08 2022
Seaside, CA
Bid Date: Apr 12 2022
Seaside, CA
--
Seaside, CA
Bid Date: Mar 21 2022
Sacramento, CA
Bid Date: Oct 18 2022
Sacramento, CA
Bid Date: Oct 18 2022
Malibu, CA
Bid Date: Oct 13 2022
Napa, CA
Bid Date: Oct 18 2022
Palo Alto, CA
--
Hayward, CA
Bid Date: Oct 18 2022
Dutch Flat, CA
Bid Date: Oct 18 2022
Recently Viewed
--
--
--
--
--
--
--
--
--
--
The best commercial construction data available. Period.
Sign up now to get instant access to project search, five projects and five companies, free.
Get the right
data with Project Intelligence
Project Shared
with
example@example.com
Choose what you would like to do.
Seen enough? Want to see more? Subscribe on your own or talk to one of our sales reps.
What is your business type?
We have a wide variety of products that are purpose built for certain business types.