Site work for a playground / park / athletic field in Daytona Beach, Florida. Completed plans call for site work for a playground / park / athletic field.

The County of Volusia, Department of Public Works, Costal Division is seeking a single, responsive and responsible bidder for the construction of a beachfront parking lot with an ADA compliant dune walkover, showers, landscaping, and lighting located at 726 North Atlantic Avenue, Daytona Beach Florida 32118. The lowest responsive and responsible bidder shall be responsible for all applicable permitting, labor, materials, equipment, tools, transportation, services, and incidentals necessary to complete all Work required by the specifications and as shown on the drawings. Each Bid shall be accompanied by a Bid bond in an amount equal to at least five percent (5%) of the Bid amount payable to the County of Volusia; as a guarantee that, if the Bid is accepted, the Bidder will execute the Contract, provide certificates of insurance in the amounts and categories required by the County and, if required, record separate performance and payment bonds in amounts and with sureties acceptable to the County, within ten (10) days after the award of the Contract. The County of Volusia reserves the right to reject any or all Bids and to waive any formality or technicality in any proposal in the interest of the County of Volusia . The County reserves the right to reject any or all Bids, or any part of any Bid, to waive any informality in any Bid, or to re-advertise for all or part of the work contemplated. The County reserves the right, prior to award of Contract, to delete from the scope of the project any item or any combination of items the aggregate Bid prices for which do not exceed twenty-five percent (25%) of the total Bid price for the project. If Bids are found to be acceptable by the County, written notice will be given to the lowest responsive and responsible Bidder of the acceptance of his/her Bid and the award of a Contract . The County reserves the right to reject the Bid proposal of a Bidder who has previously failed to perform properly or to complete contracts of a similar nature on time; Failure of the Bidder to execute a Contract and record the required bonds as provided herein within ten (10) days after a written Notice of Award has been given shall be just cause for the annulment of the award and the forfeiture of the Bid security to the County, which forfeiture shall be considered not as a penalty, but in liquidation of damages sustained. Award may then be made to the next lowest responsive and responsible Bidder or all Bids may be rejected. A monetary payment made for damages, agreed by both parties in contract which are due and payable for breach by a party. May be applied on a daily basis for as long as the breach is in effect. Cannot be imposed as an arbitrary penalty. Must meet the threshold of reasonableness. All time periods stated in the Contract Documents are of the essence of the Contract. The County and Contractor agree that any damages and losses to the County which will result from the Contractor's failure to complete the Work within the time specified (including any extensions thereof approved by the County) are impossible to accurately determine at the time of executing this Contract. Such sums as detailed in Article 2.3 of the Construction Contract are hereby agreed to be reasonable predictions of damages, which will be sustained and are specifically declared to not constitute a penalty for breach of contract. The duties and obligations imposed by the Contract Documents and the rights and remedies available hereunder and, in particular, but without limitation, the rights and remedies available to County thereunder shall be in addition to and shall not be construed in any way as a limitation of any rights and remedies available to it which are otherwise imposed or available by law, by special guarantee, or by other provisions of the Contract Documents, except for the liquidated damages clause which prohibits the County from seeking actual damages for delay in the event Contractor fails to achieve Substantial Completion within the contractually allotted time.