Scope of Work of the Contract includes the following: the removal of existing site fencing and access gate, the installation of a new precast concrete panel fence, the installation of mechanically operated access gate, and the installation of a pedestrian access gate. Each Bid must be accompanied by a Bid Bond or a certified or cashiers check, acceptable to the Owner, in an amount not less than five percent (5%) of the total amount Bid, as a guarantee that the successful bidder will enter into the Contract and execute the Bonds on the forms provided, and provide the required insurance certificates within seven (7) days after the date Contract Documents are received by the Contractor. If a certified or cashiers check is provided, the successful bidder shall deliver, at the ENGINEERS office (IDS Engineering Group, 13430 Northwest Freeway, Suite 700, Houston, Texas 77040), the original certified or cashiers check within twenty-four (24) hours of the bid opening. Bidder must submit their Bid and bid securities in compliance with Owners Order Adopting Section 49.2731 Electronic Bidding Rules and all Bids and bid securities must be submitted electronically. Bidder must register on this website in order to submit a Bid and bid security and there is no fee to submit Bids and bid securities on this website. By submitting a Bid, Bidder acknowledges and agrees that the Contract Documents may be accepted, executed or agreed to through the use of an Electronic Signature, as defined by and in accordance with Owners Electronic Signature Rules for Construction Contracts. The Owner reserves the right to reject any or all Bids and to waive all defects and irregularities in bidding or bidding process except time of submitting a Bid. The Successful Bidder, if any, will be the responsible
Bidder which in the Boards judgment will be most advantageous to the District and result in the best and most economical completion of the Project. The requirements of Subchapter J, Chapter 552, Government Code, may apply to this Bid and/or Contract and the Contractor agrees that the Contract can be terminated if the Contractor knowingly or intentionally fails to comply with a requirement of that subchapter. Completion Date: 60 Calendar Days The deadline to ask questions is 11/18/2022 12:00 AM CST
.webp)
