Site work for a water / sewer project in Derby, Connecticut. Completed plans call for site work for a water / sewer project.

The project consists of the installation of an ADA Compliant fishing pier and viewing platform located on O'Sullivan Island on the Housatonic River. The pier is located southeast from the Commodore Hull Bridge along the shore of the river. Construction shall be in accordance with the current industry construction standards, Form 818, all supplements thereto and special provisions provided herein. All proposals must be on the form furnished with the Contract Documents. The minimum rates to be paid labor of the various classifications shall be in accordance with the Davis-Bacon Act. For contracts equal to or less than $2,500, contractors are required to pay the federal minimum wage as provided in Section 6(a)(1) of the Fair Labor Standards Act. For prime contracts in excess of $100,000, contractors and subcontractors must also, under the provisions of the Contract Work Hours and Safety Standards Act, as amended, pay laborers and mechanics, including guards and watchmen, at least one and one-half times their regular rate of pay for all hours worked over 40 in a workweek. A Connecticut Department of Labor Contractors Wage Certification Form is to be submitted to the the City of Derby before the award of the contract. Bids must be accompanied by a certified check or Bid Bond in writing on forms provided by the City of Derby in the amount of at least one tenth (10%) of the amount of the Bid and payable to the orderof the City of Derby. The successful Bidder will be required to furnish and pay for a Performance Bond and a Payment Bond in the amount of one hundred percent (100%) of the Contract price. The right is reserved by the City of Derby to reject any or all Bids, to waive any informalities or defects in Bids, and to make such time extensions as may be necessary in order to review and compare Bids, to obtain such supplemental information as may be necessary to review Bids and to accept Bid(s) that, in the judgment of the City of Derby, will be in the City's best interest. The project consists of the installation of an ADA compliant fishing pier and viewing platform located on O'Sullivan Island on the Housatonic River. The pier is located southeast from the Commodore Hull Bridge along the shore of the river. The City reserves the right to decrease the Scope of Work to be done under this Contract, select bid or alternate items in its best interest, or to omit any work in order to bring the cost within available funds. Exercise by the City of the above rights shall not constitute any grounds or basis of claim for damages or for anticipated profits on work omitted.