Site work for a sidewalk / parking lot in Eastpoint, Florida. Completed plans call for site work for a sidewalk / parking lot.

DESCRIPTION OF WORK:The project consists of the construction of a wood dune walkover project located at the end of 3rd Street West, St. George Island, Franklin County, Florida, specifically between DEP Monuments R-82 and R-83. The pile-supported structure is 6-foot wide by 187.8 feet long for an area of approximately 1,127 square feet. The public is invited to attend. The meeting will be live streamed but if anyone would like to participate, they will need to attend in person. All bids shall remain firm for a period of sixty (60) days after the opening. All Bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Bid security in the amount of at least five percent (5%) of the total bid must be submitted with the bid. The bid security may be either a certified check or a proposal guaranty bond executed by a surety company authorized to do business in the State of Florida. Bid security shall be made payable to Franklin County. The successful bidder must be able to furnish a 100% Performance Bond and a 100% Labor and Materials Payment Bond, and shall begin execution of this contract within five (5) calendar days following the date of the Notice to Proceed. The completion date for this project will be a total of 60 days from the date of the Notice to Proceed presented to the successful Bidder and must be completed by April 30, 2023 . Liquidated damages for failure to complete the project on the specified date will be set at $100.00 per day. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. Any questions must be submitted to Erin Griffith at erin@franklincountyflorida.com by Thursday, January 5, 2023, at 4:00 p.m. ET (local time).