Renovation of an educational facility in Colorado Springs, Colorado. Completed plans call for the renovation of a educational facility.

Colorado Springs School District 11 is requesting proposals from Contractors to perform Potable Water Upgrade at Holmes Middle School. B.1 GENERAL The following is presented to describe the general expected vendor performance requirements. Offerors must submit how and when they are capable of supplying the required products and services and completing the work within the required time. Offerors are free to suggest other product(s) brands and models, work service procedures, or project approaches, designs, or exceptions to this general scope of work. Those exceptions must be clearly (bold, underlined, etc.) indicated in your offer. If an Offeror cannot perform as described or takes exception to any element, those exceptions must be fully described in their Offer and an alternate plan or approach presented. Award will not be based on price alone. B.1.1 The apparent silence of any scope of work/specification(s) and any supplemental amendment specifications as to any details or the omission from it of a detailed description concerning any point shall be regarded as meaning that only the best commercial practices are to prevail. Contractors are to submit written questions through Bonfire to the Contracting Office, by Noon on 11/30/2022 This solicitation document is requesting Offers from responsible/capable contractors who desire to sell to the District their products and/or services at a negotiated price. B.1.2 Clean-Up Contractor shall keep the premises free from accumulation of debris, surplus material, waste material, dirt piles and rubbish caused by the work. Contractor shall perform clean-up daily and transport rubbish to an on-site location designated by Contractor. Contractor is responsible for containment and removal. The Contractor shall at all times keep the work area, including storage areas, free from accumulations of waste materials. Before completing the work, the Contractor shall remove from the work and premises any surplus materials that are not the property of the District. Upon completing the work, the Contractor shall leave the work area in a clean, neat, and orderly condition satisfactory to the Contracting Officer and shall remove surplus material, waste material, and dirt and rubbish, tools, equipment and scaffolding. A. Final Clean-Up: 1. Exterior: In addition to items specified below, all surfaces on exterior, concrete, metal, etc., affected by the work shall be carefully and thoroughly cleaned. 2. Glass: Both sides of all glass affected by the work shall be carefully and thoroughly cleaned by professional window cleaners and left absolutely clean and free from paint, labels, grease, dirt, etc. 3. Hardware: Clean and polish all hardware affected by the work and leave clean and free from paint, grease, dirt, etc. 4. Equipment: Carefully and thoroughly clean all items or equipment, mechanical, electrical, cabinets, ductwork, etc., which have been affected by the work. B. All work areas within the area of responsibility shall be left in clean condition before being accepted by the District. The Contractor shall be required to clean only those areas which are affected by the work. It is anticipated that this will be limited to the work areas indicated on the plans, areas adjacent to the work areas which are affected by the work, the areas on the site where the Contractor's trailer(s) are located, and any other interior or exterior areas which have been dirtied or damaged by the Contractor's operations under this contract. C. Any damage caused by the Contractor shall be accomplished within the period of performance of the Contract. No extension of time will be granted to complete repair Question Deadline 11/30/2022 at 12:00 PM MT Online Portal liquidated damages, for each calendar day of delay the sum of $484.00