Renovation of a mixed-use development in El Paso, Texas. Completed plans call for the renovation of a educational facility.

The Contractor agrees to provide all the materials and fully execute and perform all the Work described in the Contract Documents and as shown or required by the Plans and described in the Specifications entitled: ESSER HVAC Replacement in High Occupancy Areas of Middle Schools and High Schools (Group 3) for The EL PASO INDEPENDENT SCHOOL DISTRICT, prepared by ASA Architects, P.C., acting as and in these contract documents entitled the Architect and shall do everything required by the Contract Documents Questions Deadline: 12/14/2022 12:00 PM (MT) The Project will be funded in whole with funds provided through the ARP ESSER grant program, authorized in the American Rescue Plan Act (ARP), which was signed into law in March 2021. The federal Department of Education has allocated funds to the states under the ESSER Program to fund grants to school districts throughout its state, including renovations or remodeling, that are necessary to the program goals of prevention of, preparation for or response to COVID-19. EPISD is a sub-recipient of the state of ESSER funding for the Project. To maintain its eligibility for such funding, the Solicitation package contains additional or different provisions, certifications and requirements than Respondents may be generally accustomed to when responding to the District's normal construction solicitations. Respondents are encouraged to examine this Solicitation and the accompanying Contract Forms and Addenda carefully, understand the terms and conditions for providing the services listed herein, and respond completely. FAILURE TO COMPLETE AND PROVIDE ANY OF THE ABOVE ITEMS MAY RESULT IN THE PROPOSAL BEING DEEMED NON-RESPONSIVE AND THEREFORE DISQUALIFIED FROM CONSIDERATION. The EL PASO INDEPENDENT SCHOOL DISTRICT reserves the right to reject any and all proposals and to waive all technicalities.