Site work and paving for a road / highway in Wewahitchka, Florida. Completed plans call for site work for a road / highway; and for paving for a road / highway.

For Stone Mill Creek Resurfacing The Gulf County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing: STONE MILL CREEK RESURFACING This project includes approximately 3.01miles of roadway resurfacing along Stone Mill Creek Road in Gulf County, FL. Completion date for this project will be 180 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $1,694.00 per day. Please place YOUR COMPANY NAME, SEALED BID, and the BID NUMBER on the outside of your envelope and include the original bid plus 2 copies. All bidders shall be FDOT Qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Construction, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and Hot Plant Mix-Bituminous Course. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. All questions must be submitted to Clay Smallwood, P.E. at csmallwood@gulfcounty-fl.gov. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County.