Demolition and site work for an educational facility in Gadsden, Alabama. Completed plans call for the demolition of a educational facility; and for site work for a educational facility.

For Demolition of Jarvis Hall for Gadsden State Community College It is the responsibility of the bidder to assure that bids are presented at the time of the bid if they choose to mail the bid. Contractors must notify the Awarding Authority if a bid is to be received by mail. General Contractor's License number and specialty must be on the envelope. A cashier's check or bid bond payable to Gadsden State Community College in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000.00, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance as required in the bid documents will be required at the signing of the Contract General Contractors will then be placed on Official Bidders List. Hard copy sets of drawings/ specifications will be available to General Contractors for purchase directly from the document printer: Alabama Graphics. Addenda and other proposal information will be issued only to holders of drawings and specifications distributed by the Architect and on the Official Bidders List. Release of contract documents to the bidder does not imply acceptance of the bidder's qualifications by the Owner or Architect. Bids received from General Contractors who are not on the Official Bidders List may not be accepted or opened. Lathan Associates Architects, P.C. makes no guarantee for plans and specifications obtained by Contractors and Vendors from sources other than the printed contract documents provided by their firm. Contractors and Vendors who base their pricing from contract documents obtained from other electronic sources, either in part or whole, do so at their own risk. Bids must be submitted on proposal forms furnished by the Architect, or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975. The Bidder must display current General Contractor's License Number on the outside of the sealed envelope in which the proposal is delivered, or it will not be considered by the Architect or Owner. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted Completion date: 90 Calendar Days.