Site work and paving for a civil project in Springtown, Texas. Completed plans call for site work for a road / highway; for paving for a road / highway; and water / sewer project.

Reconstruction of residential street including 6 water main. Quantities are as follows: 1. 820 LF of 6" PVC Water Main 2. 1,900 SY of Pavement Pulverization 3. 1,900 SY of Asphalt Pavement A bid bond in the amount of 5 percent of the bid issued by an acceptable surety shall be submitted with each bid. A certified check or bank draft payable to the City of Springtown or negotiable U.S. Government Bonds (as par value) may be submitted in lieu of the Bid Bond. Attention is called to the fact that not less than, the federally determined prevailing (Davis-Bacon and Related Acts) wage rate, as issued by the Texas Department of Agriculture Office of Rural Affairs and contained in the contract documents, must be paid on this project. In addition, the successful bidder must ensure that employees and applicants for employment are not discriminated against because of race, color, religion, sex, sexual identity, gender identity, or national origin. The lobbying certification must be submitted with the bid packet to be considered complete and responsive. All contractors/subcontractors that are debarred, suspended or otherwise excluded from or ineligible for participation on federal assistance programs may not undertake any activity in part or in full under this project. Deadline for questions is 10:00 AM on Friday, May 5th, 2023. The City of Springtown reserves the right to reject any or all bids or to waive any informalities in the bidding. Bids may be held by the City of Springtown for a period not to exceed 60 days from the date of the bid opening for the purpose of reviewing the bids and investigating the bidder's qualifications prior to the contract award. The City of Springtown is an equal opportunity employer. Maximum contract time required by the Contractor for completion of these improvements, beginning on the date specified in the Notice to Proceed, is 180 Calendar days. The contract will be awarded to the responsive, responsible Bidder submitting the lowest/best bid. The bidder selected will be notified at the earliest possible date. The locality reserves the right to reject any or all bids and to waive any informality in bids received where such rejection or waiver is in its interest. All materials and workmanship shall be subject to inspection, examination, or test by the City/County and Engineer at any and all times during manufacture or construction and at any and all places where such manufacture or construction occurs. The City/County shall have the right to reject defective material and workmanship or require its correction. Unacceptable workmanship shall be satisfactorily corrected. Rejected material shall be promptly segregated and 02/22/2023 88 removed from the Project Area and replaced with material of specified quality without charge. If the Contractor fails to proceed at once with the correction of rejected workmanship or defective material, the City/County may by contract or otherwise have the defects remedied or rejected materials removed from the Project Area and charge the cost of the same against any Monies which may be due the Contractor, without prejudice to any other rights or remedies of the City/County . CONTRACTOR and OWNER recognize that time is of the essence of this Agreement and that OWNER will suffer financial loss if the Work is not completed within the times specified in paragraph 4.02 above, plus any extensions thereof allowed in accordance with section 9(d) of the General Conditions. The parties also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by OWNER if the Work is not completed on time. Accordingly, instead of requiring any such proof, OWNER and CONTRACTOR agree that as liquidated damages for delay (but not as a penalty), CONTRACTOR shall pay OWNER $ 500.00 for each day that expires after the time specified in paragraph 4.02 for Substantial Completion until the Work is substantially complete Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in subparagraph (1) of this paragraph, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in subparagraph (1) of this paragraph, in the sum of $25 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of 40 hours without payment of the overtime wages required by the clause set forth in sub paragraph (1) of this paragraph. W ithholding for unpaid w ages and liquidated damages. HUD or its designee shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contract, or any other Federally-assisted contract subject to the Contract Work Hours and Safety Standards Act which is held by the same prim e contractor such sums as m ay be determined to be necessary to satisfy any li abilities of such contractor or subcontractor for unpaid wages and liquidated dam ages as provided in the clause set forth in subparagraph (2) of this paragraph . The CONTRACTOR agrees to make all necessary repairs, reconstruction and renewal of any part of said construction, and to furnish the labor and materials to make good and to repair any defective condition growing out of or on account of the breakage or failure of any substance or the improper function of any part of the constructed work. The CONTRACTOR shall reimburse the OWNER for the cost of all Engineering and special services required to be furnished by the OWNER which are directly attributed to the restoration of the constructed work. Said maintenance contemplates the complete restoration of the constructed work to a functional use during the said period as set forth above. It is being understood that the purpose of this section is to require the correction of all defective conditions resulting from materials furnished or work and labor performed by said CONTRACTOR under the conditions prescribed by Contract Documents. In case the said CONTRACTOR shall fail or refuse to perform as provided within ten (10) days after proper written notifications have been furnished to him by the OWNER, it is agreed that the OWNER may do said work and supply such materials and the said CONTRACTOR and Surety herein shall be subject to the liquidated damages mentioned in said Contract for each calendar day's failure on its part to comply with the terms of the said provisions of the said Contract and the Maintenance Bond any amount due the City/County under Liquidated Damages shall be deducted from the final payment due the contract . f the work is not completed within the time stipulated in the applicable bid for Lump Sum or Unit Price Contract provided, the Contractor shall pay to the City/County as fixed, agreed, and liquidated damages (it being impossible to determine the actual damages occasioned by the delay) the amount of $500.00 for each calendar day of delay, until the work is completed. The Contractor and Contractor's sureties shall be liable to the City/County for the amount thereof