Site work and paving for a mixed-use development in Burlington, Iowa. Completed plans call for site work for a municipal facility; sidewalk / parking lot; and for paving for a sidewalk / parking lot.

Description of the Proposed Work: Courthouse Parking Lots All design, services, labor, and materials necessary to construct the courthouse parking lots at 513 N. Main Street, Burlington, IA 52601. A Certified check, made payable to the County, or a Cashier's check, made payable to either the County or to the contractor, drawn upon a solvent bank or a bid bond, shall be filed with each proposal in an amount as set forth in the minimum specifications form. Cashier's check, made payable to the contractor, shall contain an unqualified endorsement to the County signed by the contractor or his authorized agent. Failure to execute a contract and file an acceptable bond and Certificate of Insurance within 30 days of the date of the approval for awarding of the contract, as herein provided, will be just and sufficient cause for the denial of the award and the forfeiture of the proposal guaranty. At the successful bidder's request, Des Moines County will issue sales tax exemption certificates through the Iowa Department of Revenue and Finance to the successful bidder and any subcontractors to enable them to purchase qualifying materials for the project free of sales tax. The County, in accordance with Title VI of the Civil Rights Act of 1964, 78 Stat. 252, 42 U.S.C. 2000d to 2000d-4 and Title 49, Code of Federal Regulations, Department of Transportation, Subtitle A, Office of the Secretary, Part 21, Nondiscrimination in Federally-assisted programs of the Department of Transportation issued pursuant to such Act, hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, or national origin in consideration for an award. COMPLETION DATE: June 23, 2023 LIQUIDATED DAMAGES: $100 per day BID BOND: $1000 All proposals must be filed on the forms furnished by the County, sealed and plainly marked. Proposals containing any reservations not provided for in the forms furnished may be rejected, and the County Board reserves the right to waive technicalities and to reject any or all bids