This is a service / maintenance or supply contract in N Richmond, California. Contact the soliciting agency for additional information.

The Respondent will be responsible for the removal of the existing wireless access points and shall return all removed equipment to the District. The Respondent is responsible for the provision and installation of Wireless Access Points at different sites throughout the district. Wireless access points may be located in classrooms, gymnasiums, auditoriums, office spaces, corridors, lunchrooms, libraries and other school rooms including outdoors in public spaces, sports fields, and others. Anticipated Notice to Proceed April 1, 2023 (dependent on E-Rate funding) Contactor’s Submittal’s due 1 Week from Notice to Proceed date Project Duration 120 Calendar Days The security shall be in an amount equal to at least Ten Percent (10%) of the amount bid. A bid shall not be considered unless one of the forms of bidder's security is enclosed. RIGHT TO REJECT ANY AND ALL QUOTES The Owner reserves the right to reject any or all bid proposals and to waive any informalities or irregularities. The vendor’s submission of a proposal is recognition of this right. LIQUIDATED DAMAGES The target dates pertaining to this project must be adhered to by the contractor or liquidated damage will be assessed by the Owner. Contractor shall be assessed the sum of Five Hundred Dollars and No Cents ($500) per day as liquidated damages for each and every calendar day the work required under the Project documents remains unfinished past the time for completion as shown on the Project Schedule.