Privately Funded
Bidding Soon
Documents Available
Publicly Funded
Addenda Available
Post-Bid
Saving Project...
Site work for a water / sewer project in Fort Myers, Florida. Completed plans call for site work for a water / sewer project.
**As of April 24, 2023, project was awarded to Earth View, LLC. awarded amount is $669,584.60.** BASIN 4 STORMWATER SYSTEM MAINTENANCE AND REPAIRS Any bid received by the DISTRICT after the above date and time shall remain unopened. General Project Description (for detailed description please refer to the full ITB document): SCOPE OF WORK: The work on this contract generally consists of the following: The Proposer shall furnish all materials, tools, supplies, heavy equipment, vehicles, and labor necessary for the maintenance, reporting, cleaning, and repair as needed of all stormwater drains. The Proposer shall bear all costs associated with the Project. Stormwater cleaning shall be performed with a vacuum truck or other approved method. The District intends to award a Construction Contract Agreement to the best qualified CONTRACTOR that offers a proposal that is deemed to be in the District's best interest. The District is not responsible for expenses incurred prior to award. The DELIVERABLES shall include the cost of: 1. Meetings with GSCDD staff to discuss Stormwater drain repair reports. 2. A written report and a portable drive of all findings and containing a video recording of all Storm Drains cleaned or repaired. Additional work may be requested by the DISTRICT to be performed as negotiated based on pricing provided in this bid, as well as other items as deemed commensurate for the requested scope of work. The DISTRICT will require a Bid Security/Bond and a Public Construction Bond on this project. The District reserves the right, in its sole judgment in the best interest of the District, to waive any informalities in any bids; to make award(s) including multiple awards; to waive any non-substantive, in District's sole judgment, irregularity or technicality in bids received, and/or to reject any or all bids. BASIN 4 STORMWATER SYSTEM MAINTENANCE AND REPAIRS Any bid received by the DISTRICT after the above date and time shall remain unopened. General Project Description (for detailed description please refer to the full ITB document): SCOPE OF WORK: The work on this contract generally consists of the following: The Proposer shall furnish all materials, tools, supplies, heavy equipment, vehicles, and labor necessary for the maintenance, reporting, cleaning, and repair as needed of all stormwater drains. The Proposer shall bear all costs associated with the Project. Stormwater cleaning shall be performed with a vacuum truck or other approved method. The District intends to award a Construction Contract Agreement to the best qualified CONTRACTOR that offers a proposal that is deemed to be in the District's best interest. The District is not responsible for expenses incurred prior to award. The DELIVERABLES shall include the cost of: 1. Meetings with GSCDD staff to discuss Stormwater drain repair reports. 2. A written report and a portable drive of all findings and containing a video recording of all Storm Drains cleaned or repaired. Additional work may be requested by the DISTRICT to be performed as negotiated based on pricing provided in this bid, as well as other items as deemed commensurate for the requested scope of work. The DISTRICT will require a Bid Security/Bond and a Public Construction Bond on this project. The District reserves the right, in its sole judgment in the best interest of the District, to waive any informalities in any bids; to make award(s) including multiple awards; to waive any non-substantive, in District's sole judgment, irregularity or technicality in bids received, and/or to reject any or all bids. Please direct questions to Randy Paniagua, Contracts Manager: bids@gatewaydistrict.org
Award
Water / Sewer
$669,585.00
Public - County
Site Work
Trades Specified
Division 00 - Lorem Ipsum
Find More Local Projects
Within 75 Miles of This Project
One Low Price
- One license and one market
- Details and key contacts on all bidding projects
- Organize your pipeline with a digital bid board
- Automatically match opportunities to your profile
- Saved searches deliver daily project leads to your email inbox
Market Pricing Around
- All Starter Product functionality
- Access to all documents (plans, specifications, and addenda)
- Access to planning projects
- Access to contact information
- Ability to Export
You’ve Reached the Free View Limit
Want to see more project and bidder data in your market? Check out our product options and see what works best for you and your business.
Come back in [[refresh_days]] to get [[project_count]] more free projects.
March 17, 2023
April 17, 2023
Multiple Locations, Fort Myers, FL
Related To This Project
Fort Myers, FL
Bid Date: Mar 30 2023
Fort Myers, FL
Bid Date: Mar 30 2023
Fort Myers, FL
Bid Date: Mar 16 2023
Fort Myers, FL
Bid Date: Apr 05 2023
Fort Myers, FL
Bid Date: Mar 15 2023
Fort Myers, FL
Bid Date: Mar 27 2023
Fort Myers, FL
Bid Date: Mar 31 2023
Fort Myers, FL
Bid Date: Mar 28 2023
Fort Myers, FL
Bid Date: Mar 17 2023
Fort Myers, FL
Bid Date: Mar 16 2023
Fort Myers, FL
Bid Date: Mar 21 2023
Fort Myers, FL
Bid Date: Mar 22 2023
Fort Myers, FL
Bid Date: Mar 15 2023
Fort Myers, FL
Bid Date: Mar 02 2023
Recently Viewed
--
--
--
--
--
--
--
--
--
--
The best commercial construction data available. Period.
Sign up now to get instant access to project search, five projects and five companies, free.
Get the right
data with Project Intelligence
Project Shared
with
example@example.com
Choose what you would like to do.
Seen enough? Want to see more? Subscribe on your own or talk to one of our sales reps.
What is your business type?
We have a wide variety of products that are purpose built for certain business types.