Renovation of a military facility in Cherry Point, North Carolina. Completed plans call for the renovation of a military facility.

Project No.: 6967850 (Clauses incorporated in Base Contract apply to this solicitation) Title: Repair Sanitary Sewer Dahlia Lane, Slocum Housing NAICS Code and Standard Size: 238220, Plumbing, Heating, and Air-Conditioning Contractors, 16.5 Million Contract Completion Date: All work shall be completed within 120 calendar days after award Estimated Cost Range: Between $ 250,000.00 and $500,000.00 Wage Determination: General Decision NC20230065 01/06/2023 Liquidated Damages: $259.00 per calendar day of delay Basis for Award: Lowest Price Proposal Acceptance Period: 90 calendar days after receipt of offers Site Visit: 11 April 2023 at 10:00 AM Contractors are to meet at the FEAD office, Building 87, MCAS Cherry Point This will be the ONLY Government Scheduled Site Visit for this Project. Bond Requirements: Bid bonds are required in accordance with FAR 28-101-4. An electronic copy of your bid bond must be submitted with your proposal. An electronic copy of your bid bond will be requested from the apparent low upon confirmation of their price and must be submitted to the FEAD office within one (1) week from time of request. Failure to submit an electronic copy of your bid bond with your proposal will result in your proposal being deemed nonresponsive and your proposal removed from consideration. In accordance with FAR Clause 52.228-15 Performance and Payment Bonds--Construction and FAR Clause 52.228-13 Alternate Payment Protections, Payment and/or performance bond(s) will be requested at the time of award. BONDS TO BE PROVIDED ELECTRONICALLY, SEALS MUST BE VISIBLE o No bonds are required for proposals less than $40K. o Proposals valued at $40K and greater will require a payment bond only. o Proposals valued at $150K and greater will require a bid bond, a payment bond, and a performance bond. FAR Clause 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 is applicable for this solicitation. REPAIR SANITARY SEWER DAHLIA LANE, REQUEST FOR PROPOSAL SLOCUM HOUSING MCAS Cherry Point, North Carolina Project No. 6967850 Page 3 of 11 DFARS 252.225-7059 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region--Certification, which includes a certification requirement stated below. DFARS 252.225-7060, Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region, which prohibits contractors from providing any products mined, produced, or manufactured wholly or in part by forced labor from XUAR or from an entity that has used labor from within or transferred from XUAR as part of any forced labor programs. Please either return an email or add the certification statement on your proposals stating the following: "Certification from (Please enter your company name here) that you have made a good faith effort to determine that forced labor from XUAR was not or will not be used in the performance of a contract resulting from this solicitation" Proposal Due Date/Time: 04 May 2023 by 1200 local time E-Mail Address for Proposals and Requests for information (RFIs): 1. roicc_chpt_ktr_bids@navy.mil 2. linda.b.clark14.civ@us.navy.mil 3. ericka.j.bishop.civ@us.navy.mil *note: Proposals must be sent to ALL of the above email addresses. Subject line should contain the project number and contra120ctor information. Requests for Information (RFIs): RFIs must be submitted email addresses above. The cut off for RFIs is 24 April 2023 by 0900 in order to process all inquiries by the proposal due date. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document. Question Deadline 04/24/2023 at 9:00 AM ET E-Mail Address for Proposals and Requests for information (RFIs): 1. roicc_chpt_ktr_bids@navy.mil 2. linda.b.clark14.civ@us.navy.mil 3. ericka.j.bishop.civ@us.navy.mil Project Description The work includes the repair of a sanitary sewer manhole, ancillary piping and fittings, associated demolition, and subsequent restoration as required to complete the work, and incidental related work. The work is located at MCAS Cherry Point, approximately as indicated. The exact location will be shown by the Contracting Officer.