Renovation of an educational facility in Northport, Alabama. Completed plans call for the renovation of a educational facility.

Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. Drawings and Specifications may be examined at the office of the Architect, Ward Scott Morris Architecture, Inc., 1606 Paul Bryant Drive, Tuscaloosa, Alabama, and the office of the Construction Manager, Hall-Taylor Construction, Inc., 4703 Fosters Industrial Lane, Tuscaloosa, Alabama. Bid documents may be obtained from the Construction Manager, Hall-Taylor Construction, Inc., 4703 Fosters Industrial Lane, Tuscaloosa, Alabama. Other sets for contractors, and sets for dealers, may be obtained with the same deposit, which will be refunded as above, less cost of printing, reproduction, handling, and distribution. Electronic PDF copies of bid documents may be procured from the office of the Construction Manager free of charge. To obtain electronic PDF copies of the bid documents, contact Clay Smalley at Hall-Taylor Construction at clays@halltaylorconstruction.com. Bid bonds are to be issued by an acceptable bonding company licensed to do business in the State, with a Power of Attorney, to confess judgment thereon, with the understanding that it shall guarantee that the bidder shall not withdraw his bid for the guarantee period of sixty (60) days after the scheduled closing time for the receipt of bids. The bidder shall be liable to the Owner for the full amount of the bid guarantee as liquidated damages and not as a forfeit or as a penalty. The bid bond and certified checks on unsuccessful bidders will be returned upon awarding the contract or rejection of all bids, in no event, later than the number of days in the guarantee period from the opening of proposals. That of the successful bidder will be returned when formal contract and bonds are accepted and approved. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted.