Site work for a water / sewer project in Utica, Illinois. Completed plans call for site work for a water / sewer project.

Contract Award Date: Sep 21, 2023 Contract Award Number: W912EK23C0041 Task/Delivery Order Number: Contractor Awarded Unique Entity ID: VPLVZEFWPLK9 Contractor Awarded Name: Midwest Construction Company Contractor Awarded Address: Nebraska City, NE 68410 USA Base and All Options Value (Total Contract Value): $6,825,454.00 Illinois River Basin, Starved Rock Pool, LaSalle County, IL, Starved Rock Breakw ater NESP See Section 01 11 00 Summary of Work 100% Woman-Ow ned Small Business (WOSB) Set-Aside NAICS: 237990 Other Heavy and Civil Engineering Construction Small Business Size Standard: $45,000,000.00 Estimated Range: $5,000,000.00 - $10,000,000.00 Completion days: 365 consecutive calendar days. INSTRUCTION TO BIDDERS The Rock Island District has implemented the below procedures for all current bid openings. Electronic Submission of Bids: For this IFB Solicitation, the Rock Island District is requesting all bids be submitted via email to the Contracting Officer and Contract Specialist. NO HARD COPY BIDS WILL BE ACCEPTED. Contracting Officer - Mr. Jeffrey R. Voss, email at jeffrey.r.voss@usace.army.mil Contract Specialist - Mr. Eric J. Gaul, email at eric.j.gaul@usace.army.mil In the subject of the e-mail - the solicitation and Project Name shall be provided. The Contracting Officer or Contract Specialist will send an email acknowledging receipt. Please note, the Firewall can cause a delay in receipt of email, so be sure to allow time for the delay. The Bid Opening is currently scheduled for Tuesday, 05 September 2023 at 2:00PM CST. The Contracting Officer and Contract Specialist will begin downloading bids FOUR HOURS BEFORE BID OPENING TIME, which is the bid receipt cutoff time. All bids received after 10:00 AM CST on Tuesday, 05 September 2023 will be considered late. Audio Teleconference Bid Opening Information: Bid Opening will be held on Tuesday, 05 September 2023 at 2:00 PM CST. Please use the following call-in information to attend the meeting: Toll-Free: 844-800-2712 Access Code: 2762 653 0997 Following the conclusion of the bid opening, the Bid Abstract will be uploaded to SAM website under this solicitation, within 24 hours. Bid Bonds (Offer Guarantee) should be submitted electronically with the Bid Package as per the scheduled Bid Opening on Amendment. Per Class Deviation 2020-O0016, Electronic signatures and electronic, mechanically-applied, or printed dates may be used and shall be considered original signatures and dates. In addition, a Corporate Seal is not required, the SF 28 need not be sworn and notarized and a written authorization of the release signed by the surety is acceptable in lieu of the notarized authorization of release by the surety. Original Certified Bonds need not be submitted at time of bid. HOWEVER, the Rock Island District reserves the right to request the Original Certified Bonds, if deemed necessary to verify their authenticity. For any Questions please contact: Contracting Officer - Mr. Jeffrey R. Voss Phone: 309-794-5914 Contract Specialist - Mr. Eric J. Gaul Phone: 309-794-5093 Technical inquiries and questions relating to this solicitation are to be submitted via Bidder Inquiry in ProjNet at (https://www.projnet.org) No Later Than (NLT) 12:00 PM Central Time on 18 August 2023. To submit or review inquiry items, prospective vendors will need to use the Bidder Inquiry Key presented below and follow the instructions listed below the key for access. A prospective vendor who submits a comment /question will receive an acknowledgement of their comment/question via email. Another email to the same address will notify the prospective vendor once the reply is available for viewing. The Bidder Inquiry Key is: JG2BW6-KB72TJ *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.