Renovation of an educational facility in Priv, Ontario. Completed plans call for the renovation of a educational facility.

The National Research Council Canada, Uplands Campus, has a requirement for a project that includes: Work under this contract covers the replacements of the boilers at Building U66 and installation of new boilers at building U66A located on the Upland Campus of the National Research Council of Canada Selection Criteria Potential bidders will be rated in a combination of technical score and price rating. For this project the total score will be established as follows: Technical rating 40% = Technical Score (Points) Price rating 60% = Price Score (Points) Total Score = Max. 100 points Mandatory requirements Failure to meet the mandatory requirement will render the proposal as non-responsive and no further evaluation will be carried out. Item Mandatory Requirements Proposal Page #(s) 1 The Bidder must have a minimum of ten (10) years' experience in the execution of mechanical project, and as a contractor providing construction services comparable to this tender. Provide a company profile and relevant history as described in item #1 of the evaluated technical criteria. 2 The Bidder must supply a CV for the proposed construction site supervisor and Project Manager. 3 Bidder must demonstrate to be a member of MCA or any Recognized Mechanical Contractors association in Ontario.(Provide Copy of certificate) Include this table with your proposal and indicate the proposal page where the information can be found. Any Bidder which fails to meet any of the following mandatory requirements will be considered non-compliant and will not be given further consideration. Each requirement should be addressed separately. valuated Technical Criteria Item Evaluated Technical Criteria Proposal Page # (s) Max Score 1 Demonstrated experience by the Proponent providing general mechanical construction services relevant to this project. Include 2 comparable projects completed by the proponents firm in the last 10 years with reference names & phone numbers. Maximum 1 page per project. Evaluations will take into account relevance compared to the scope of this tender (up to 3 point for each example project) and whether the reference was satisfied with the work completed (up to 1 point for each example project). It is the responsibility of the bidder to ensure the contact information for the reference is accurate. If the reference cannot be reached or declines to provide input the proponent will received a score of 0/1 for that example. 8 2 Qualifications and overall experience of proposed construction site supervisor and Project Manager. CV will be scored on the basis of related experience (up to 2 points), experience acting as a construction site supervisor on federal government construction projects (up to 2 points) and experience on federal government Project for the Manager (up to 3 points). Include detailed examples of 2 past projects for the construction site supervisor who was in that position for at least 80% of the duration of those projects. CV should be no longer than 3 pages. 7 3 Provide company profile for asbestos abatement sub-contractor. Include 3 comparable projects completed by the proponents firm in the last 5 years that demonstrate experience relevant to the asbestos abatement scope of work for this tender. Evaluation will consist of (1 point) for 10-15 years in business, (2 points) for over 15 years in business and up to 1 point for each comparable projects (up to 3 Points). 5 4 The Proponent should provide their construction schedule for this project, from award to final completion, detailing major milestones, critical path elements, and associated timelines. Schedule evaluation will be based on whether it meets the completion date noted in the tender documents (up to 2 points), and if the tasks and associated timelines demonstrate the contractor understands the scope of work (up to 3 points). 5 Total 25 Include this table with your proposal and indicate the proposal page where the information can be found. As proof of attendance, at the site visit, the Contracting Authority will have an Attendance Form which MUST be signed by the bidder's representative. It is the responsibility of all bidders to ensure they have signed the Mandatory Site Visit Attendance form prior to leaving the site. Proposals submitted by bidders who have not attended the site visit or failed to sign the Attendance Form will be deemed non-responsive. The parties understand that the Procurement Ombudsman appointed pursuant to Subsection 22.1 (1) of the Department of Public Works and Government Services Act will review a complaint filed by the complainant respecting the administration of the Contract if the requirements of Subsection 22.2(1) of the Department of Public Works and Government Services Act and Sections 15 and 16 of the Procurement Ombudsman Regulations have been met. To file a complaint, the Office of the Procurement Ombudsmai1 may be contacted by e-mail at boa.opo@boa-opo.gc.ca, by telephone at 1-866-734-5169, or by portal The Departmental Representative or his designate for this project is: Brent Minard Brent.Minard@nrc-cnrc.gc.ca Telephone: (613) 668-3862 Contracting Authority for this project is: Collin Long Collin.Long@nrc-cnrc.gc.ca The estimated contract period will be 6 month(s), with a proposed start date of 2023/05/31. Bid value not released for publication