Renovation of a municipal facility in Orlando, Florida. Completed plans call for the renovation of a municipal facility.

Work under this contract will consist of replacement of the eight uninterrupted power supply systems at the Orange County Courthouse. The Estimated Cost for this project is $1.400,000.00 Untimely questions are unable to be submitted in the question and answer module, thereafter respondents raising critical concerns must email michelle.black@ocfl.net. Critical clarifications may be made via addenda, however, untimely questions may not be considered. A Bid, Payment and Performance Bond are a requirement when the offer/contract amount exceeds $100,000. Respondents shall attach an electronic copy of their bid bond for responsiveness. Submission of the bid bond, along with a certified and effectively dated copy of the power of attorney, shall be completed and signed by all required parties and submitted on the form provided in the solicitation. Submittal of a bid bond less than 10% of the total estimated contract amount for base period, shall result in the bid being deemed non-responsive. In order to be acceptable to the County, the Surety company issuing the Bid Bond shall meet and comply with the minimum standards described in #Bond Requirements, "Qualifications of Surety Companies". Failure to submit a Bid Bond from a Surety Company meeting these minimum standards shall result in rejection of the offer. Liquidated Damages: Should the Contractor fail to substantially complete all Work under this Contract and make the project available for beneficial use on or before the date stipulated for Substantial Completion (or such later date as may result from extension of time granted by County), he shall pay and/or the County may retain from the compensation otherwise to be paid to the Contractor, as liquidated damages, the sum of $500.00 for each consecutive calendar day that terms of the Contract remain unfulfilled beyond date allowed by the Contract, which sum is agreed upon as a reasonable and proper measure of damages which County will sustain per diem by failure of Contractor to complete work within time as stipulated; it being recognized by County and Contractor that the injury to County which could result from a failure of Contractor to complete on schedule is uncertain and cannot be computed exactly. In no way shall costs for liquidated damages be construed as a penalty on the Contractor. For each consecutive calendar day that the work remains incomplete after the date established for Final Completion, the County will retain from the compensation otherwise to be paid to the Contractor the sum of $500.00. This amount is the mutually agreed upon minimum measure of damages the County will sustain by failure of the Contractor to complete all remedial work, correct deficient work, clean up the project and other miscellaneous tasks as required to complete all Work specified and this amount of liquidated damages is in addition to the liquidated damages prescribed above for failure to timely achieve Substantial Completion. Question Deadline 05/22/2023 at 5:00 PM ET