Renovation of a service station / car wash facility in Millersville, Maryland. Completed plans call for the renovation of a service station / car wash facility.

Solicitation Summary Construct the Fall Protection Needed for the New Railcars and Modify the Existing Wheel Truing Machine Pit to Receive the New Wheel Truing Machine. This Contract is for the installation of a fall protection system consisting of fall arrest equipment, monorail, motorized swing arm, elevated platform with access stairs with support columns. Additional ancillary items include but are not limited to power connection to an existing panel and miscellaneous painting. The contract will include the selective demolition of existing shop floor, pit wall and relocation and refurbishment of existing railings. In the event that the Contractor fails to complete the specified work within the specified number of days after Notice to Proceed, with the exception of extensions granted by change order, liquidated damages in the amount of $1,295.00 will be assessed pursuant to General Provisions Article GP-8.09 for each calendar day the completion of the specified work is delayed. The Contractor shall pay to the Administration the applicable amount specified and pursuant to General Provisions Article GP-8.09 as liquidated damages for every additional calendar day in excess of the number of days prescribed. The Administration may deduct the sum of liquidated damages from any monies due or that may become due the Contractor under the Contract, or if such monies are insufficient, the Contractor or sureties thereof shall pay to the Administration any deficiency within 30 calendar days. Pre-bid Conference at 10:00 AM. Wednesday, May 10, 2023. via zoom. The call-in number is 443-409-5228 Conference ID # 228270125 #. If you would like to join via Microsoft Teams, send your request to CWILLIAMS@MDOT.MARYLAND.GOV. A site visit will be conducted at 2:30 PM on Wednesday, May 10, 2023. Interested vendors must RSVP by sending company name, point of contact and email address to Cwilliams@MDOT.Maryland.Gov. Questions regarding the work should be directed in writing to Christie Williams At Cwilliams@MDOT.Maryland.Gov. Questions concerning this solicitation must be received no later than Wednesday, May 17, 2023 at the close of the business day. No interpretations other than written shall be binding on the Administration The Administration reserves the right to reject any and all bids and/or waive technical defects if, in its judgment, the interests of the Administration so require. DBE Participation (%) 5.0 Project Cost Class D - $1,000,000 to $2,500,000 Completion of All Contract work 430 *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.