Site work and paving for a road / highway in Port St Joe, Florida. Completed plans call for site work for a road / highway; and for paving for a road / highway.

**As of October 31, 2023, the award amount is not yet determined. The Gulf County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing: COUNTY ROADWAY PROJECT PHASE 2 This project includes approximately 6.3 miles of roadway resurfacing in the Highland View community in Gulf County, FL. Liquidated damages for failure to complete the project on the specified date will be set at $2,650.00 per day. The outside of your envelope and include the original bid plus 2 copies. All bidders shall be FDOT Qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Construction, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and Hot Plant Mix-Bituminous Course. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. All questions must be submitted to Clay Smallwood, P.E. at csmallwood@gulfcounty-fl.gov. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County.