Site work and outdoor lighting for a mixed-use development in Victoria, Texas. Completed plans call for outdoor lighting for a playground / park / athletic field; for site work for a water / sewer project; and playground / park / athletic field.

Reference Number 0000328860 The selected respondent contractor shall furnish and install the following improvements for the DOG PARK IMPROVEMENTS PHASE II: - Water utility improvements, as detailed and specified on Sheet C4.1 "Victoria Dog Park Water Utility". Improvements include the purchase and install of approximately 1,360 LF of 2" PVC SCH80 water main, hose bibs and pipe casing as noted. All items shall be complete in place as shown on plan; -Solar light improvements, as detailed and specified on Sheet E201 "Electrical Site Plan". Improvements include the purchase and installation of nine solar lights on a concrete pole base; - Pet fountain improvements, as detailed and specified on Sheet L2.1 "Materials Site Plan". Improvements include the purchase and installation of a pet drinking fountain; the saw cut and removal of concrete as noted; providing water line connection to the pet drinking fountain from an existing 2-inch water line and providing a 4 inch perforated drain pipe connection from the pet drinking fountain -All other appurtenances necessary to complete the Project. Question Acceptance Deadline 09/07/2023 02:00 PM CDT Questions are submitted online No All requests for additional information or clarification concerning this proposal must be submitted in writing Participation Requirements - Airport Concessionaires Disadvantaged Business Enterprise (ACDBE) - Business Concern - Disadvantaged Business Enterprise (DBE) - Minority Business Participation - Native American Participation - Small Business Participation - Service-Disabled Veteran Owned - Women-Owned Business Participation Award Requirements - All or None Award - Reserve Rights to Award by Line Item Bonding Requirements - Bid Bond 5 % - Performance Bond 100 % - Payment Bond 100 % Each Proposal must be accompanied by a certified check, cashier's check, or an approved Bid Bond in the amount of 5% of the Proposal cost, payable to the City of Victoria without recourse, as a guarantee the Respondent will enter into a contract and execute 100% performance and payment bonds on the forms provided, within ten (10) days after the contract has been awarded. - The proposed budget for construction costs for this Project is $85,200.00 Project Duration - The City has established a target commencement date for construction activities as 10 days after the Notice of Proceed letter. The projected completion date is estimated to be 120 days - The Project is located at the intersection of Memorial Drive and Young Drive, Victoria, Texas 77901. *The City reserves the right to modify the commencement date, subject to Owner and Contractor availability, phase the construction of the Project, or modify the schedule as needed and determined by the City due to modifications in .