Site work and addition to a mixed-use development in North Bay, Ontario. Completed plans call for the addition of a 4,190-square-foot, two-story above grade municipal facility.

Design-Build Services for Two-Story Expansion to ONTC's Motor Coach Stores and Office Administration Facility. Ontario Northland Transportation Commission (ONTC) is seeking proposals for a two-story design build structural steel building solution to expand our stores operation and office space building at our North Bay, Ontario Motor Coach facility. We require approximately 2000 sq. ft. of additional warehouse space to accommodate parts, racking, skids, forklifts, and shipping and receiving equipment. The anticipated completion date for the project is March 15, 2024. The building is located at 567 Wallace Road, in North Bay, Ontario. ONTC is seeking "turnkey" proposals from Respondents who can complete the entire project from start to finish. ONTC will not entertain the sale of building packages, kits, or proposals that require ONTC to hire additional resources or subcontractors to complete the project. ONTC is seeking proposals for the construction and addition of a new two-story structural steel building with approximate dimensions of 32'x60'. The main floor is to be an open-type warehouse building and the second story will consist of office space. Contractor shall design and construct this facility to an environmentally responsible manner, utilizing sustainable design concepts, systems and materials to the maximum extent practical, in order to provide a facility that minimizes adverse effects on the exterior environments, enhances the quality of the indoor environment, and minimizes consumption of energy, water, construction materials, and other resources. The Respondent will provide: All architecture, engineering, design, and construction of the new two-story structural steel building, including but not limited to: Architecture Geotechnical engineering, Structural Engineering, Mechanical Engineering, -Electrical Engineering, Civil Engineering (above and underground site services) Architects and Engineers working on this project shall have minimum 8 years' experience individually and be registered to practice in the province of Ontario. 1.All architecture, engineering, design, and construction for modification of the existing Stores Warehouse and second floor offices building where the two will meet/attach. 2.Engineered plans, Geotechnical reports, surveys, and storm water management plan for all construction required for the installation of the new building. 3.All construction must meet the National Building Code of Canada, the National Fire Code of Canada, the Ontario Building Code, Ontario Fire Code and applicable codes and design standards as a minimum. 4.The Respondent will be required to supply all labour, material, equipment, travel, living expenses, permits, fees, and all others to complete the project. 1. The Contractor will be responsible for demolition, removal, and proper disposal of structures and any contents of the stores building. 2. All debris created by the execution of the work shall be removed progressively from the site. 3. Contractor is responsible for all temporary shoring, bracing and supports required during the project. 4. Non-hazardous and masonry materials and any excavated material will be disposed of on an on-site location identified by ONTC. 5. Contractor shall ensure all sewer and sanitary drains within the work area are protected and with filter cloth throughout the project if needed. Official bid documents must be obtained from www.merx.com and bid submissions must be done through the Merx platform.