Demolition, site work and new construction of a water / sewer project in Leander, Texas. Completed plans call for the demolition of a water / sewer project; for the construction of a water / sewer project; and for site work for a water / sewer project.

Reference Number 0000330209 The City of Leander, herein after "City", seeks to enter into an agreement with a qualified Individual, Firm or Corporation, herein after "Respondent", to provide construction services for the delivery of the of the Wastewater Collection System Lift Station Improvements Phase 1, Lift Station #6. BACKGROUND NARRATIVE: The Work consists of the demotion of the existing lift station (LS #6), construction of a replacement lift station, installation of a pre-assembled Pump Mate unit, installation of a genset, and other appurtenant work. Question Acceptance Deadline 09/26/2023 at 5:00 PM CT Questions are submitted online No For questions or clarifications of specifications, you may contact: Kelly Wenzel Contract Manager City of Leander Telephone: 512-528-2978 kwenzel@leandertx.gov Bid Security: Bids must be accompanied by a bid bond with Power of Attorney attached or cashiers check of five percent (5%) of the total amount bid (sum of all bid items) made payable to the City of Leander. Performance and Payments Bonds: Successful respondent shall deliver to City both a Payment Bond and a Performance Bond no later than the 10th day after the agreement has been executed both for the Project price. Penal sums for both bonds shall each be equal to the agreed upon Project price. Liquidated Damages: Liquidated damages shall apply in the amount of one-thousand dollars ($1,000.00) per calendar day for each day past the agreed upon delivery date that the Project completion may be late. Project Timeline: Respondent shall provide estimated project timeline for delivery of Project. The not-toexceed deadline for project delivery must be four hundred (400) days substantial completion, and four hundred and thirty (430) days final completion