Site work and paving for a sidewalk / parking lot in Homewood, Alabama. Completed plans call for site work for a sidewalk / parking lot; and for paving for a sidewalk / parking lot.

Bids are invited upon the following work, but not limited to, as follows: Construction of a sidewalk along 26th Avenue S and Central Avenue, and items required for the construction of a sidewalk. Bids must be accompanied by a certified check or bank draft payable to the order of Jefferson County, Alabama negotiable U.S. Government Bonds (at par value) or a satisfactory Bid Bond executed by the bidder and an acceptable surety, in the amount equal to five percent (5%) of the total of the bid amount but not to exceed $10,000.00, for the construction of Rosedale Sidewalk Improvements. The bid security is to become the property of the owner in the event that: (1) the bidder fails to meet any of the qualifications required in the bid specifications stated herein; (2) the bidder misrepresents or falsifies any information required to be provided by the owner; (3) for any reason that the bidder fails to qualify, causing his bid to be withdrawn or rejected and such withdrawal or rejection results in delay or substantial additional expense to the owner; (4) the contract and bond are not executed within the time set forth, as liquidated damages for the delay and additional expense of the owner caused thereby. The bid security is to become the property of the owner in the event that: (1) the bidder fails to meet any of the qualifications required in the bid specifications stated herein; (2) the bidder misrepresents or falsifies any information required to be provided by the owner; (3) for any reason that the bidder fails to qualify, causing his bid to be withdrawn or rejected and such withdrawal or rejection results in delay or substantial additional expense to the owner; (4) the contract and bond are not executed within the time set forth, as liquidated damages for the delay and additional expense of the owner caused thereby. Bid documents are on file and will be available for examination at the JEFFERSON COUNTY DEPARTMENT OF COMMUNITY SERVICES, 716 Richard Arrington Jr. Blvd N, Suite A-430, Birmingham, Alabama 35203; at the BIRMINGHAM CONSTRUCTION INDUSTRY AUTHORITY, 601 37th Avenue South, Birmingham, Alabama 35222; at the Office of Sentell Engineering Inc.639 Black Bears Way, Tuscaloosa, Alabama 35401. Addenda and other proposal information will be issued only to holders of drawings and specifications distributed by the Engineer and on the Official Bidders List. Release of contract documents to the bidder does not imply acceptance of the bidders qualifications by the Owner or Engineer. General Contractors who obtain drawings and wish to withdraw from the Bidders List must do so in writing to the office of the Engineer prior to the bid date. Bids received from General Contractors who are not on the Official Bidders List may not be accepted or opened. Sentell Engineering makes no guarantee for plans and specifications obtained by Contractors and Vendors from sources other than the printed contract documents provided by their firm. Contractors and Vendors who base their pricing from contract documents obtained from other electronic sources, either in part or whole, do so at their own risk. Bids must be submitted on proposal forms furnished by the Engineer or copies thereof, issued either with the original contract documents or by addendum. General Contractors shall not use Proposal Forms other than those provided in the contract documents. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975. The Bidder must display current General Contractor's License Number on the outside of the sealed envelope in which the proposal is delivered, or it will not be considered by the Engineer or Owner. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. Bidders are advised that submitted bids bind the bidders to the "Bid Conditions Setting Forth Affirmative Action Requirements for all Non Exempt Federal and Federally assisted Construction Contracts to be awarded in Jefferson, Shelby and Walker Counties, Alabama, "also known as the Birmingham Hometown Plan. Attention is called to the fact that not less than the minimum salaries and wages as set forth in the contract documents must be paid on this project, and that the contractor must ensure that employees and applicants for employment are not discriminated against because of their race, color, sex, age, religion, national origin, disability, or veteran status. All bidders be advised that this contract is subject to Section 3 of the Housing and Urban Development act of 1968, as amended, (12 USC l701U) which if it is in excess of $100,000, requires that to the greatest extent feasible, opportunities for training and employment be given lower income residents of the project area and contracts for work in connection with the project be awarded to business concerns which are: (1) 51 percent or more owned by section 3 residents; or (2) Whose permanent, full-time employees include persons, at least 30 percent of whom are currently section 3 residents, or within three years of the date of first employment with the business concern were section 3 residents; or (3) That provides evidence of commitment to subcontract in excess of 25 percent of the dollar award of all subcontracts to be awarded to business concerns that meet the qualifications set forth in paragraphs (1) or (2) in this definition of section 3 business concern. The Jefferson County Commission reserves the right to reject any or all bids or to waive any informalities in the bidding. This project will be funded in its entirety (100%) with Federal Community Development Block Grant Funds. No Bid may be withdrawn for a period of sixty (60) days from the date of the opening of bids to allow the Jefferson County Commission to review the bids and investigate the qualifications of bidders, prior to awarding the contract.