**As of December 26, 2023, Project has been awarded. Award amount is $97,183.17** The Project base bid consists of repairing existing cracks in the surface, leveling of depressed areas in the existing surface as needed, cleaning and preparing the courts, installation of rust block and installation of a new acrylic coating system on four (4) tennis courts (Courts 1-4) at the Community Pool on Springfield Avenue in New Providence, New Jersey. The Contractor shall be aware that the acrylic coating system cannot be applied when the surface temperature is below 50 F or when fog, rain, or high humidity is imminent. All work on this contract must be completed within thirty (30) calendar days from issuance of a Notice to Proceed. The alternate bid consists of repairing existing cracks in the surface on four (4) tennis courts (Courts 5-8) at the Community Pool on Springfield Avenue in New Providence, New Jersey. Proposals must be made on the standard Proposal forms in the manner designated in the Contract documents, must be enclosed in sealed envelopes bearing the name and address of the Bidder and the name of the project on the outside and be addressed to the Borough of New Providence and must be accompanied by a Statement of Consent of Surety from a surety company authorized to do business in the State of New Jersey and acceptable to the Municipality and either a Bid Bond or a Certified Check drawn to the order of "Borough of New Providence" for not less than ten percent (10%) of the amount bid, except that the check shall not exceed $20,000.00. The successful bidder is hereby notified that a performance bond and labor and material (payment) bond for the full amount of this project is required. The award of the Contract for this project will not be made until the necessary funds have been provided by the Owner in a lawful manner. The Owner reserves the right to require a complete financial and experience statement from prospective bidders showing that they have satisfactorily completed work of the nature required before furnishing proposal forms or specifications, or before awarding the Contract. Proposals for this Contract will only be accepted from bidders who have properly qualified in accordance with the requirements of the Contract documents. The right is also reserved to reject any or all bids or to waive any informalities where such informality is not detrimental to the best interest of the Owner. Further, the Owner reserves the right to abandon the project and reject the bids entirely if any legal or state or federal administrative action is taken against the Owner which could delay or jeopardize the project from commencing. The right is also reserved to increase or decrease the quantities specified in the manner designated in the Specifications. *The list of planholders and/or interested bidders is not being tracked by the stakeholders involved with this project. If you are an interested contractor and wish to be listed as a bidder, please notify our editorial staff at addtobidlist@constructconnect.com.
.webp)
