Site work and asbestos abatement for an educational facility in Aberdeen, South Dakota. Completed plans call for site work for a educational facility; and for asbestos abatement for a educational facility.

In accordance with the provisions of SDCL 34-44-8, all bidders and contractors are hereby notified that this project does involve asbestos containing materials (greater than 1%). Proper procedures shall be followed in handling asbestos containing materials. This statement constitutes the warning and specifications required by SDCL 34-44- 8. The owner or those representing the owner shall not be held responsible or liable for any injury to any individual resulting from his or her handling of or proximity to such materials. Further, the owner shall not be responsible for any extra cost to the bidder or contractor beyond that specified and included in the bid resulting directly or indirectly from handling of or proximity to these materials. Bidders are further instructed that no asbestos containing materials are to be installed in this project. The contractor is cautioned that hidden materials unknown to the owner and inaccessible for testing may be found during the demolition work of this project which may be asbestos containing materials. Proper procedures shall be followed upon discovery of these materials. The owner or those representing the owner in any capacity shall not be held responsible or liable for any injury or cost to any person resulting from handling of or proximity to such materials. In lieu of a certified check as a bid guarantee, a bid bond of ten percent (10%) of the total amount of the bid, including all add alternates, may be furnished by the Contractor The BOR reserves the right to reject any or all bids and to waive any irregularities therein. The State reserves the right to reject any bid proposal, the right to waive technicalities, and the right to reject all bid proposals and advertise for new bid proposals, if in the sole judgment of the State the rejection or waiver will promote the best interest of the State. Final Completion Date: February 29, 2024