Renovation of a mixed-use development in Riverdale, Illinois. Completed plans call for the renovation of a educational facility.

As of December 28, 2023, this project has not yet been awarded. The project is expected to be awarded on January 31, 2024. Gymnasium Sound System Various Schools for Dolton Riverdale School District 148 Riverdale, Illinois Work will be let under one contract to the lowest qualified bidder. Contractors desiring to obtain plans are required to register with the Architect, complete a bidder information form, and provide a A.I.A. Document A-305 (Contractor Qualification Statement). Contractors shall make deposit check payable to: Dolton Riverdale School District 148. IF NO BID IS SUBMITTED, DEPOSIT CHECK IS FORFEITED. Each bid must be accompanied by a bid bond, or a certified check payable to the order of the Owner, certified by a responsible bank for an amount not less than (10%) of the total amount of the bid, as a guarantee that the bidder, if awarded the Contract, will furnish a satisfactory performance and payment bond, execute the Contract and proceed with the work. Upon failure to do so, the bidder shall forfeit the amount deposited as liquidated damages and no mistakes or errors on the part of the bidder shall excuse the bidder or entitle him to a return of the aforementioned amount. A 100% Performance Bond and a Labor/Material Bond will be required of the successful bidder, written by a Surety approved by the Owner. Bidders will examine the plans and specifications and also the location in which said work is to be done and judge for themselves all the circumstances and surrounding conditions affecting the cost and nature of the work, and all bids will be presumed to be based on such examination, familiarity and judgment. Not less than the prevailing wage shall be paid for labor on the work to be done as required by law. The successful bidder will be required to comply with the provisions of all State of Illinois and federal laws concerning public works projects as well as the State of Illinois Human Rights Act and the regulations of the Illinois Human Rights Commission. The Board of Education, Dolton Riverdale School District 148 reserves the right to accept or reject any or all bids, waive any or all irregularities or technicalities in the bid, and award the bid in the manner that best serves the interests of the Owner.