Site work for a playground / park / athletic field in Olanta, South Carolina. Completed plans call for site work for a playground / park / athletic field.

Basketball Court at Olanta Park. the amount of five percent (5%) of the proposed total contract price shall accompany the bid. These deposits shall take the form of certified check, cashier's check or bond executed by a corporate surety licensed under the laws of this state. The cashier's check or certified check shall be deposited to the County's account if the successful bidder fails to enter into the proposed contract within ten (10) days after the award. The time limit that is set for this project is six (6) months but not to exceed one (1) year. In order to ensure a sincere and reasonable effort on the Contractor's part to accomplish the work in a timely fashion, delay damages due to inconveniences to the owner for work not being accomplished on time will be at the rate of five hundred dollars ($500.00) per day. The Contractor should realize that delays due to bad weather, materials, and such, not under the control of the Contractor will be considered by the Engineer for time extension. Florence County is accepting bids from licensed and qualified contractors to provide bids for one (1) full-court basketball court; furnish and install two commercial grade basketball goals, with a 4in. thick concrete surface located at Olanta Park Basketball Court in Olanta, SC. Florence County reserves the right to accept or reject, in whole, in part, together or separately, any and all responses as appears in its judgment to be in the best interests of the County, or to waive any and all technicalities and informalities in determining the action of each bid. The Owner reserves the right to increase or decrease the amount of work under the Contract at the unit prices quoted in the bid received from the successful bidder. Question Deadline 01/24/2024 at 4:00 PM ET No binding interpretation of the meaning of the documents or any questions relating to the bid will be made to any bidder orally prior to the receipt of bids. Any request for such interpretation or questions shall be made in writing via Vendor Registry. To be given consideration, such requests must be received.