Renovation of a playground / park / athletic field in Vienna, Virginia. Completed plans call for the renovation of a playground / park / athletic field.

The Town of Vienna, VA seeks bids from qualified HVAC contractors to remove and replace the Trane HVAC unit located at 247 Nutley Street NW, Vienna, VA 22180. This unit is located on the ground behind the building. Background Located in Northern Virginia and approximately 14 miles from Washington D.C., the Town of Vienna is an incorporated town within Fairfax County- adjacent to Tysons Corner (Northeast), Oakton and Fairfax City (Southwest), Merrifield/Mosaic District (Southeast) and Reston (Northwest). The Town is 4.4 square miles and home to approximately 16,473 residents. Vienna is primarily a residential community with at least 71 percent of the land developed for residential purposes, excluding rights-of-way. The Town has approximately 3.5 million square feet of commercial and industrial space--60 percent is used for professional office space, 30 percent of the space is used for retail, and the remaining 10 percent is used for industrial purposes. Vienna is also home to a diverse business base serving independent retailers and even the nation's largest credit union, Navy Federal Credit Union. Question Submission Deadline: March 28, 2024, 10:00am While mandatory, the purpose of this meeting is to allow potential offerors an opportunity to present questions and obtain clarification relative to this solicitation. Any changes resulting from this meeting will be issued in the question and answer section or in a written addendum to the solicitation. The Town of Vienna reserves the right to reject any and all bids or to accept the bid(s) which, in its judgment, will be for its best interest. NO BID MAY BE WITHDRAWN FOR A PERIOD OF NINETY (90) DAYS SUBSEQUENT TO THE DATE OF THE BID OPENING. Any bid may be withdrawn PRIOR to the scheduled time for bid opening or authorized postponement thereof. Contract Renewal The resulting contract will begin once the award is made and the contract is signed. The contractor will have 120 days to complete the work once a notice to proceed is provided. The liquidated damages incurred by the Owner due to the Contractor's failure to complete the Work within the Contract Time, including any extensions thereof, shall be $250.00 per day for each consecutive calendar day beyond the Contract Time (Sundays and all holidays included) for which the Contractor shall fail to complete the Work.