Renovation of a mixed-use development in El Paso, Texas. Completed plans call for the renovation of a educational facility.

The University of Texas at El Paso is seeking Competitive Sealed Proposals for the project entitled Library - Transformer Replacement. Deadline for Questions Monday, 04/01/24 @ 5:00 p.m. MST CSP Electronic Submittal Due Date Tuesday, 04/09/24 by 10:00 a.m. MST Evaluation Completion Date 04/15/24 (estimated) Notice of Intent to Award 04/16/24 (estimated) Work involves replacement of owner-provided transformer that services the University Library Building as denoted in the sealed construction documents. The transformer is currently located about 3 miles from the job location and is part of job scope. It is the responsibility of contractor to document/protect existing condition and protect delivery pathway affected by scope. Staging and laydown area will be coordinated with selected contractor. Submit one (1) original hard copy of the HUB Subcontracting Plan as described in Section 1.13 in a separate envelope to the location listed in Section 1.5.2, and one (1) PDF copy of the HUB Subcontracting Plan (HSP) via email to Benjamin Alvarez, the UTEP HUB Coordinator at email address: baalvarez@utep.edu The Owner designates the following person, as its representative and Point-of-Contact for this RFP. Respondents shall restrict all contact with the Owner and direct all questions regarding this RFP, including questions regarding terms and conditions, to the Point-ofContact person. Anna Goodwin, Technical Buyer The University of Texas at El Paso Facilities Services Physical Plant Complex 3120 Sun Bowl Drive El Paso, TX 79968 Ph: (915) 747-8143 Fax: (915) 747-7118 Email: amgoodwin@utep.edu (preferred communication) Submit one (1) original hard copy of the Proposal/Qualifications