Renovation of a municipal facility in Sharon, Pennsylvania. Completed plans call for the renovation of a municipal facility.

Contracts will be awarded with the understanding that the Contractor, prior to submission of bid, has become acquainted with the requirements of the Contract Documents, condition of the site, the building (interior spaces, exterior envelope), terrain, soil conditions, all utilities in existence (including those to which connections are to be made), all other conditions of the Contract and has obtained all information necessary for completion of the work on or before the date specified and shall assume all risks resulting from any changes in the conditions which may occur during the progress of the work The Owner reserves the right to reject any and all bids when such rejection is in the interest of the Owner, and to reject the bid of any Bidder, who in the Owner's judgment, is not in position to perform the Contract. The general prevailing minimum wage rates, as determined by the Pennsylvania Department of Labor and Industry, Bureau of Labor Law Compliance for Prevailing Minimum Wage Predeterminations,shall be paid for each craft or classification of all workers needed to perform the Contract during the anticipated term thereof, refer to Section 007343 for the rates as issued for this Project. The Bidder shall submit his Bid with the understanding that (1) the Work shall be completed in accordance with Section 011000 "Scheduling Requirements of the Work", and the Final Project Completion Date(s) shall be as stated therein, (2) the time for the completion of the Work shall be considered of the essence of this Contract, and (3) for the costs of extra inspection, salaries of contingent forces and other expenses entailed by the Owner by delay in completing the contract, said Owner shall be entitled to liquidated damages in the following amounts: Final Project Completion Date $500.00 Final Project Closeout Completion Date $400.00 Bids shall include a Bid Security Bond or Certified Check, payable to the City of Sharon, in an amount of ten percent (10%) of the bid, in accordance with Instructions to Bidders, as included in the Contract Documents