Site work and paving for a mixed-use development in San Antonio, Texas. Completed plans call for site work for a road / highway; for paving for a road / highway; sidewalk / parking lot; sidewalk / parking lot; and water / sewer project.

Construction for this project is expected to improve safety, connectivity, and accessibility for all users by expanding the bicycle network, reducing the occurrence of fatalities and serious injuries along our roadways using proven safety countermeasures, creating and maintaining the City's Quiet Zones and using low impact development (LID) when possible. Elements of the construction contract include but are not limited to sidewalks, on and off-street bicycle improvements, paving, flatwork, medians, signage, pavement markings, rain gardens, vegetation, and other storm water improvements. The Deadline for questions is scheduled for April 16, 2024 at 4:00PM (CT). The consultant's construction estimated for this contract is: $3,999,860.00 Owner Rights: City may reject any or all bids/proposals submitted by Bidder/Respondents whenever such rejections are deemed in the best interest of City to do so. City also may reject any part of a Bidder/Respondent's bid/proposal unless, the bid/proposal has been qualified as provided in Paragraph 5.1.3 above. City reserves the right to reject any bid/proposal if the evidence submitted by, or investigation of, such Bidder/Respondent fails to satisfy City that such Bidder/Respondent is responsible to carry out the obligations of the Contract and to complete the Work contemplated therein. Liquidity Damages: Should a successful Bidder/Respondent fail to execute the Contract and Bonds and provide the required proof of insurance coverage(s) to City within ten (10) calendar days after the date of the Project's award and the transmittal of the Contract Documents (if applicable) by City to Contractor, said Proposal Guaranty shall become the property of City, not as a penalty but as liquidated damages resulting from a Project's delay and the resulting administrative damages suffered by City, as a result of the successful Bidder/Respondent failing to enter into the awarded City Contract. Bond Notes: Each bid/proposal shall be accompanied by an original Bid/Proposal Bond issued by a corporate surety company licensed to conduct business in the State of Texas, for the stated solicitation and in the amount of not less than five percent (5%) of the greatest total amount of the bid/proposal, payable without recourse to the order of the City of San Antonio, Texas. The Bid/Proposal Bond must be signed by the Bidder/Respondent, surety company, and witnesses. Failure to submit the Bid/Proposal Bond with the required signatures will deem the Bidder/Respondent's bid/proposal non-responsive. The forms of security submitted by Bidder/Respondent shall serve as a guarantee, if awarded the Contract; Bidder/Respondent promptly will enter into an Agreement with City, as required by the Contract Documents, and execute Performance and Payment Bonds on provided City forms. Bidder/Respondent acknowledges, accepts and agrees City shall not accept Performance and/or Payment Bonds not provided to City on a City-provided form. Project construction may include but is not limited to: removal and replacement or installation of concrete curbs, sidewalks, driveways, concrete retaining walls-combination type, and curb ramps, minor asphalt replacement, topsoil, sodding, tree pruning, removal and/or replacement, sign relocation, pavement markings, bicycle facility construction or retrofit, construction activities within railroad right-of-way and any other items required due to the site conditions to accomplish the project scope. This is a non-site specific contract, and task orders issued can be as small as $2,000.00. Project locations and plan details will be incorporated into this contract by task order over the life of the contract. The quantities included in this contract are only to be used in the determination of the low qualified bidder. They are not to be used in determining the quantity of materials to be ordered for work under this contract. The contractor shall accept all task orders assigned, regardless of size.