Site work, paving and outdoor lighting for a mixed-use development in Naugatuck, Connecticut. Completed plans call for site work for a road / highway; for outdoor lighting for a road / highway; for paving for a road / highway; sidewalk / parking lot; sidewalk / parking lot; sidewalk / parking lot; water / sewer project; and water / sewer project.

additional bid open note: Dial by your location +1 929 205 6099 US (New York) +1 646 518 9805 US (New York) Question Deadline 05/09/2024 Every request for such interpretation shall be in writing, addressed to James Stewart, Borough of Naugatuck Department of Public Works, 246 Rubber Avenue, Naugatuck, CT 06770 or emailed to JStewart@naugatuck-ct.gov. To be given consideration, such requests must be received at least seven (7) days prior to the date fixed for the opening of bids. The project consists of construction of approximately 800 feet of municipal roadway, demolition of a stormwater pumping station, major drainage and sidewalk reconstruction on Old Firehouse Road, construction of a pedestrian corridor between Church Street and Old Firehouse Road, installation of sidewalk pavers, fencing, curbing, lighting, street trees, and other amenities within the Borough's downtown. Construction shall be in accordance with the Borough of Naugatuck's Design and Construction Standards, Form 818 (2020), all supplements thereto and special provisions provided herein. All proposals must be on the form furnished with the Contract Documents Per CONN. GEN. STAT. 4b-91, all bidders for this State Funded project must be prequalified through the Department of Administrative Services (DAS) Construction Contractor Prequalification Program for the Contractor Classification: SITEWORK. The right is reserved by the Borough of Naugatuck to reject any or all Bids, to waive any informalities or defects in Bids, and to make such time extensions as may be necessary in order to review and compare Bids, to obtain such supplemental information as may be necessary to review Bids and to accept Bid(s) that, in the judgment of the Borough of Naugatuck, will be in the Borough's best interest. No Bidder may withdraw their bid within (90) days after the actual date of the opening thereof. The contractor who is selected to perform this State project must comply with CONN. GEN. STAT. 4a-60, 4a-60a, 4a-60g, and 46a-68b through 46a-68f, inclusive, as amended by June 2015 Special Session Public Act 15-5. State law requires a minimum of twenty-five (25%) percent of the state-funded portion of the contract be set aside for award to subcontractors holding current certification from the Connecticut Department of Administrative Services ("DAS") under the provisions of CONN. GEN. STAT. 4a-60g. (25% of the total state-funded value with DAS-certified Small Businesses and 6.25% of the total state-funded value with DAS-certified Minority-, Women-, and/or Disabled-owned Businesses.) The contractor must demonstrate good faith effort to meet the 25% set-aside goals. The minimum rates to be paid labor of the various classifications shall be in accordance with the current schedule of wages established by the State Labor Commissioner as provided in the General Statutes of Connecticut, as revised. The Contract Wage Certification Form is to be submitted to the Labor Commissioner before the award of the contract.